Loading...
HomeMy WebLinkAboutResolution - 1854 - Contract - Ed Lampe Building Contractor - Fire Station, 96Th St & Ave X - 10/11/1984October 11, 1984 Resolution #1854 Agenda Item 37 KJ:cl RESOLUTION BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF LUBBOCK: THAT the Mayor of the City of Lubbock BE and is hereby authorized and directed to execute for and on behalf of the City of Lubbock a Contract between the City of Lubbock and Ed Lampe Building Contractor, Inc., for a Fire Station to be located at 96th Street and Avenue X, attached herewith, which shall be spread upon the minutes of the Council and as spread upon the minutes of this Council shall constitute and be a part of this Reso- lution as if fully copied herein in detail. Passed by the City Council this 11th day of October ,1984. ALAN NRY, MA 0 ATTEST: Ra ette Boyd, City Secretary APPROVED AS TO CONTENT: 7ZB1�;t Tom Foster, Fire Chief APPROVED AS TO FORM: K'en Johnsc.6, Assistant City Attorney THE STATE OF TEXAS COUNTY OF LUBBOCK Before me _ Theo We 9a ge b 1 e I a Notary Public in and for Lubbock County, Texas on this day personally appeared TW i 1 a e u t I I 111111C 1:„ ,.r,+ of the Southwestern Newspa- pers Corporation, publishers of the Lubbock Avalanche -Journal — Morning, Evening and Sunday, who being by me duly sworn did depose and say that said newspaper has been published continuously for more than fifty-two weeks prior to the first insertion of this — 1 e 111,111 I ,.;tet i c No. _ 940666 at Lubbock County, Texas and the attached print- ed copy of the {tee jai q o t i Ge is a true copy of the original and wasprinted in the Lubbock Avalanche -Journal on the following dates: September 2nd & 16 t hg 1984 Account Manager LUBBOCK AVALANCHE -JOURNAL Southwestern Newspapers Corpor4;tion Subscribed and sworn to before me this __ 17. -day of S_o p t a llnb r 19-84 00 THEO W SAGESIEL FORM 58-10 Notary Public in and for the State of Texas My Commission Expires May 8, 1985 RESOLUTION 1854 Fidelityand Deposit Company HOME OFFICE OF MARYLAND BALTIMORE, MD. 21203 - STATUTORY PAYMENT BOND PURSUANT TO ARTICLE 5160 OF THE REVISED CIVIL STATUTES OF TEXAS AS AMENDED BY ACTS OF THE 56TH LEGISLATURE, 1959 (Penalty of this bond must be 100% of Contract amount) KNOW ALL MEN BY THESE PRESENTS: That ---- ------ --------- -------Buldl.%Q1,Xr��t4X1__.�1�.i.,.Luk2�S2�kr'PX�S - - (hereinafter called the Principal), as Principal, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation organized and existing under the laws of the State of Maryland, with its principal office in the City of Baltimore, Maryland, (hereinafter called the Surety), as Surety, are held and firmly bound unto Cit• - of -Lubbock, Lubbock, Texas (hereinafter called the Obligee), in the amount of. � .h ed forty-nine thousands _six ------•--- --- for the one and no/100ths------------------------- Dollars 49, 631.00 hundred ._...X ----- payment whereof, the said Principal and Surety bind themselves, and their heirs, administrators, executors, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has entered into a certain written contract with the Obligee, dated the 22nd.................................. ............. ................. ........dayof..........._................October•--__----•-----•-------•-----•---19. $4 . to construct Fire Station # 14, 96th and Avenue X, Lubbock, Texas which contract is hereby referred to and made a part hereof as fully and to the same extent as if copied at length herein. NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the said Principal shall pay all claimants supplying labor and material to him or a subcontractor in the prosecution of the work provided for in said contract, then, this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, HOWEVER, that this bond is executed pursuant to the provisions of Article 5160 of the Revised Civil Statutes of Texas, and all liabilities on this bond to all such claimants shall be determined in accordance with the provisions of said Article to the same extent as if it were copied at length herein. IN WITNESS WHEREOF, the said Principal and Surety have signed and sealed this instrument this ._ _............... 22nd ._...----- ._..... ......... day of ........... October ............................. 19 ... 84 __ WITNESS : .._.................. _. iv. ..._...._.._.....__._..imlvnniox sii..j ATTEST: (IF CO ORATION) Ed Build' Ed Build' ..-ontractor, Inc.(SEAL) '.--•-••--•••-------------_ .(SEAL) .............. •..-•--•-••----•---------- .,...-----------.._._.........__(SEAL) .............................. _.............................................. .. (SEAL) Principal FIDELITY AND DEPOSIT COMPANY OF MARYLAND Surety J�41� ........-._..........__...........__....._.... By.. --e. ' Curtis Coxon Attorney-zn-Fact- C6050a(TX) 2M, 3-76 100409 ;__ l Cf) ®a� .01 HZ 30 4,IVHHH NO W °H a f� v The FIDELITY AND DEPOSIT COMPANY OF MARYLAND o FIDELITY AND DEPOSIT 'COMPANY CompaNt's HOME OFFICES: BALTIMORE, MD. 21203 POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, and the FIDELITY AND DEPOSIT COMPANY, corporations of the State of Maryland, by C. M. PECOT, JR. I I Vice -President, and Ce W.' ROBBINS Assistant Secretary, in pursuance of authority granted by Article VI, Section 2 of the respective By -Laws of said Companies, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect of the date thereof, do hereby nominate, constitute, and a Texas ................ �...........................� PPoint Curtis Coxon of Lubbock, the true and lawful agent and Attorney -in -Fact of each, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds and undertakings ... EXCEPT bonds on behalf of Independent Executors, Community Survivors and Community Wardians.......... s .mil the executiut► of Such hoods r,r undettoi,rug, nt pursuance of these presents, shall be as binding upon said Companies, as fully and arnply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the respective Companies at their offices in Baltimore, Md., in their own proper persons. This power of attorney revokes that issued on behalf of Curtis Coxon and R. N. Garritson, dated, November 27, 1979• IN WITNESS WHEREOF, the said Vice -Presidents and Assistant Secretaries have hereunto subscribed their names and affixed the Corporate Seals of the said FIDELITY AND DEPOSIT COMPANY OF MARYLAND and the FIDELITY AND DEPOSIT COMPANYthis .....• ..............6 -nth..........---........................ day of .............. J'Aly-....................................... A.D. 19 ... 83 ........ ATTEST: FIDELITY AND DEPOSIT COMPANY O ARYLAND tEAL By 1. ............ ............................. Assistant Secretary see -President FIDELITY AND DEP IT COMPANY SEAL n ��..Lt.?.1 ..�-�-ust.......... By .................... ..............f.............................. .l uistattt Secruary ice -President STATE OF MARYLAND CITYoFBALTIMORE as*• On this 6th ' day of July , A.D. 19 83. before the subscriber, a Notary Public of the State of Maryland, in and for the City of Baltimore, duly commissioned and qualified, came the above-named Vice -Presidents and Assistant Secretaries of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND and the FIDELITY AND DEPOSIT COMPANY, tome personally known to be the individuals and officers described herein and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Companies aforesaid, and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies, and that the said Corporate Seals and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal at the ' y of Ili ore the day a year first above written. rein .............. ...... I/ ...'..... Public ... ...................... ...... _ +ran` My commission expires ......JVly-..1•a.-1986....... . ............. CERTIFICATE - I, the undersigned Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND and the FIDELITY AND DEPOSIT COMPANY do hereby certify that the original Power of Attorney of which the foregoing is a full, true and correct copy, is in full force and effect on the date of this certificate; and I do further certify that the Vice -Presidents who executed the said Power of Attorney were Vice -Presidents sPPeciallrr authorized by thF�e Boards of Directors to appoint any Attorneyin•Fact as provided in Article VI, Section 2 of the respective By -Laws of the FI DELITY,, AND DEPOSITCOMPANY OF MARYLAND and the FIDELITY AND DEPOSIT COMPANY. This certificate may be signed by facsimile under and by authority of resolutions of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 16th day of July, 1969 and of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY at a meeting duly called and held on the 2nd day of November, 1978. RESOLVED: "That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company, whether made heretofore or hereafter, whenever appearing upon a certified copy of any Power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed.' 0� �-// IN TESTIMONY WHEREOF, I have herrreunto subscribed my name and affixed the corporate seals of the said Companies, this.......... ........... day o(..... .............. 4w tr%)-~or--168-50117 FOR YOUR PROTECTION LOOK FOR THE F&D WATERMARK EXTRACT FROM BY-LAWS OF FIDELITY AND DEPOSIT COMPANY OF MARYLAND "Article VI, Section 2. The President, or any Executive Vice -Presidents, or any of the Senior Vice -Presidents or Vice -Presidents specially authorized so to do by the Board of Directors or by the Executive Committee, shall have power, by and with the concurr- ence of the Secretary or, any one of Assistant Secretaries, to appoint Resident Vice -Presidents; Assistant Vice -Presidents; and At- tornies-in-Fact as the business of the Company may require, or to authorize any person or persons to execute on behalf of the Company any bonds, undertakings, recognizances, stipulations, policies, contracts, agreements, deeds, and releases and assignments of judgments, decrees, mortgages and instruments in the nature of mortgages, and also all other instruments and documents which the business of the Company may require, and to affix the seal of the Company thereto.". EXTRACT FROM BY-LAWS OF FIDELITY AND DEPOSIT COMPANY "Article VI, Section 2. The President, or any one of the Executive Vice -Presidents; or any one of the additional Vice -Presidents specially authorized so to do by the Board of Directors or by the Executive Committee; shall have power, by and with 'the con- currence of the Secretary or any one of the Assistant Secretaries,. to appoint Resident. Vice -Presidents, Assistant Vice -Presidents, Resident Assistant Secretaries and Attorneys -in -Fact as the business of the Company may require, or to authorize any person or per- sons to execute on behalf of the Company any bonds, undertakings, recognizances, stipulations, policies, contracts, agreements, deeds, and releases and assignments of judgments, decrees, mortgages and instruments in the nature of mortgages, and also all other in- struments and documents which the business of the Company may require, and to affix the seal of the Company thereto." !'„ S1 ° i , .r - NAME AND ADDRESS OF AGENCY ' COMPANIES AFFORDING COVERAGES Coxon'and Company P.C. Box 6704 COMPA A Lubbock, Texas 79413 ETTER"Y Home Insurance Company COMPAN Y B Canal LETTER NAME AND ADDRESS OF INSURED Ed Lampe Building Contractor, Inc. COMPANY LETTER C National Surety Corporation P.O. BOX 6122 COMPANY D Lubbock, Texas 79413 LETTER COMPANY LETTER This is to certify that policies of insurance listed below have been issued to the insured named above and are in force at this time. Notwithstanding any requirement, term or condition of any contract or other document with respect to which this certificate may be issued or may the insurance pertain, afforded by the policies described herein is subject to all the terms, exclusions and conditions of such policies. COMPANY LETTER TYPE OF INSURANCE POLICY NUMBER POLICY Limits of Liabilit in Thousan s - GENERAL LIABILITY EXPIRATION DATE EACH AGGREGATE OCCURRENCE $ $ BODILY INJURY COMPREHENSIVE -FORM ® PREMISES—OPERATIONS ® EXPLOSION AND COLLAPSE PROPERTY DAMAGE $ $ HAZARD IN UNDERGROUND A HAZARD PRODUCTS/COMPLETED GA1531118 10-1-85 _ OPERATIONS HAZARD ® CONTRACTUAL INSURANCE ®BROAD FORM PROPERTY BODILY INJURY AND PROPERTY DAMAGE s 500 s 500 DAMAGE ® COMBINED INDEPENDENT CONTRACTORS ® PERSONAL INJURY PERSONAL INJURY $ AUTOMOBILE LIABILITY IN COMPREHENSIVE BODILY INJURY (EACH PERSON) $ FORM © BODILY INJURY $ A OWNED HIRED GA1531119 10-1-85 (EACH ACCIDENT) PROPERTY DAMAGE BODILY NON $ -OWNED INJURY AND PROPERTY DAMAGE s 500 EXCESS LIABILITY COMBINED B ©UMBRELLA FORM BODILY INJURY AND ❑ OTHER THAN UMBRELLA XS007470 10-1-85 PROPERTY DAMAGE $ s FORM COMBINED $24001000.00 WORKERS' COMPENSATION A and MIA60592-0110-1-85 STATUTORY EMPLOYERS' LIABILITYs 100, 000.00 OTHER (EACH ACCIDENT) C $1,500,000 at job construction Builders Risk MSF5078055 Continuous site DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES Cancellation: Should any of the above desc�ed policies be cancelled before the expiration date thereof, the issuing com- pany will endeavor to mail days written notice to the below named certificate holder, but failure to mail such notice shall impose no obligation or liability of any kind upon the company. NAME AND ADDRESS OF CERTIFICATE HOLDER: DATE ISSUED: October 15 1984 City of Lubbock Lubbock,Texas AUTHORIZ REPRESENTATIVE ACORD 25 (1J9) THE AMERICAN INSTITUTE OF ARCHITECTS AIA Document A101 Standard Form of Agreement Between Owner and Contractor where the basis of payment is a STIPULATED SUM 1977 EDITION THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION Use only with the 1976 Edition of AIA Document A201, General Conditions of the Contract for Construction. This document has been approved and endorsed by The Associated General Contractors of America. AGREEMENT made as of the 22nd day of October in the year of Nineteen Hundred and eighty-four BETWEEN the Owner: The City of Lubbock, Texas and the Contractor: Ed Lampe, Building Contractor, Inc. A corporation of Lubbock, County of Lubbock and the State of Texas. The Project: Fire Station No. 14 96th St. and Avenue X Lubbock, Texas The Architect: Atcheson, Cartwright & Associates Architects, Engineers, Planners 4010 Ave: R �ubbock, Texas 79412 The 0-wner and t e Contractor agree as set forth below. Copyright 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, ® 1977 by the American Institute of Architects, 1735 New York Avenue, N.W., Washington, D. C. 20006. Reproduction of the material herein or substantial quotation of its provisions %,ithout permission of the AIA violates the copyright lama's of the United States and will be subject to legal pro�rcution. AIA DOCUMENT A101 • OWNER -CONTRACTOR AGREIMENT • ELEVENTH EDITION • JUNE 19:7 • AIAe C19 7 • THE AMERICAN INSTITUTE Of ARCHIIECTS, 1135 NLI1' YORK AVE.. N.W., 1YASHINGTON, D. C. 20006 A101-1977 1 ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement, the Conditions of the Contract (General, Supplementary and other Conditions), the Drawings, the Specifications, all Addenda issued prior to and all Modifications issued after exe- cution of this Agreement. These form the Contract, and all are as fully a part of the Contract as if attached to this Agreement or repeated herein. An enumeration of the Contract Documents appears in Article 7. ARTICLE 2 THE WORK The Contractor shall perform all the Work required by the Contract Documents for (Here insert the caption descriptive of the Work as used on other Contract Documents.) Fire Station.No. 14 96th St. & Avenue X Lubbock, Texas ARTICLE 3 TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION The Work to be performed under this Contract shall be commenced and, subject to authorized adjustments, Substantial Completion shall be achieved not later than (Here insert any special provisions for liquidated damages relating to failure to complete on time.) 240 calendar days thereafter AIA DOCUMENT A101 - OWNER -CONTRACTOR AGREEMENT - ELEVENTH EDITION - JUNE 1977 - AIAe C1977 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D. C. 20006 A101-1977 2 ARTICLE 4 CONTRACT SUM The Owner shall pay the Contractor in current funds for the performance of the Work, subject to additions and deductions by Change Order as provided in the Contract Documents, the Contract Sum of Two hundred fourty nine thousand, seven hundred thirty one dollars (249,731.00) The Contract Sum is determined as follows: (State here the base bid or other lump sum amount, accepted alternates, and unit prices, as applicable.) Base Bid $240,903.00. Add Alternate No. 1 3,850.00 Add Alternate No. 2 4,978.00 ARTICLE S PROGRESS PAYMENTS Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as pro- vided in the Contract Documents for the period ending the day of the month as follows: Not later than fifteen days following the end of the period covered by the Application for Payment ninety five percent ( 95 %) of the portion of the Contract Sum properly allocable to labor, materials and equipment incorporated in the Work and ninety five percent ( 95 %) of the portion of the Contract Sum properly allocable to materials and equipment suitably stored at the site or at some other location agreed upon in writing, for the period covered by the Application for Payment, less the aggregate of previous payments made by the Owner; and upon Substantial Completion of the entire Work, a sum sufficient to increase the total payments to ninety five percent ( 95 %) of the Contract Sum, less such amounts as the Architect shall determine for all incomplete Work and unsettled claims as provided in the Contract Documents. (11 not covered elsewhere in the Contract Documents, here insert any provision for limiting or reducing the amount retained after the Work reaches a certain stage of completion.) Payments due and unpaid under the Contract Documents shall bear interest from the date payment is due at the rate entered below, or in the absence thereof, at the legal rate prevailing at the place of the Project. (Here insert any rate of interest agreed upon.) Usury laws and requirements under the federal Truth in lending Act, similar state and local consumer credit laws and other regulations at the Owner's 1nd Contractor's principal places of business, the location of the Project and elsewhere may affect the validity of this provision. Specific legal advice should x obtained with respect to deletion, modification, or other requirements such as written disclosures or waivers.) AIA DOCUMENT A101 - OWNER -CONTRACTOR AGREEMENT - ELEVENTH EDITION - )UNE 1977 - AIAe 01977 - THE AMERICAN INSTITUTE Of ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D. C. 20006 A707-7977 3 ARTICLE 6 FINAL PAYMENT final payment, constituting the entire unpaid balance of the Contract Sum, shall be paid by the Owner to the (Contractor when the Work has been completed, the Contract fully performed, and a final Certificate for Payment has been issued by the Architect. ARTICLE 7 MISCELLANEOUS PROVISIONS 7.1 Terms used in this Agreement which are defined in the Cbnditions of the Contract shall have the meanings designated in those Conditions. t 7.2 The Contract Documents, which constitute the entire agreement between the Owner and the Contractor, are listed in Article 7 and, except for Modifications issued after execution of this Agreement, are enumerated as follows: (List below she Agreement, the Conditions of the Contract (General, Supplementary, and other Cundaiunsl, the Drawings, the Specihcaduns, and any Addend, and accepted ahernates, showing page or sheet numbers in all cases and dates where applicable.! This Agreement including Performance Bond and Material Payment Bond. Notice to Bidders . . . . . . . . . . . . . . . Pages Instructions to Bidders . . . . . . . . . . . . . 1 1 Proposal . . . . . . . . . . . . . . . . . . . . . 3 Wage Rates . . . . . . . . . . . . . . . . 1 Foundation Investigation . . . . . . . . . . . 11 General Conditions . . . . . . . . . . . . . . . 19 Supplementary Conditions 4 Certificate of Insurance (Form) 1 Statutory Performance Bond (Form) . . . . . . . . 2 Statutory Payment Bond (Form) . . . . . . . . . . 2 Specifications Division 1 through 16 as indexed Drawings: A-1 of 10 through A-10 of 10; S-1 of 4 through S-4 of 4; ME -1 of 3 through M-3 of 3; E-1 of 2 and E-2 of 2 Addendum No. 1: 1 page, dated Sept. 24, 1984. This Agreement entered into as of the day and year first written above. OWNER CONTRACTOR airy of T ibbnnk TexaG -Edam pe, Building Contractor, Inc. Lubboc T as Lubb , Texas BY BY Alan Henry, Mayor Edward Lampe, President - AIA DOCUMENT A101 • OWNIR-CONIRACIOR AGI(E1ntIN1 • HIVINIH IUlllu% )UNL 1977 • AIAS C1977 • 1HE AMIRICAN INS117UIf Or ARCHITICIS, 17j5 NI\1 YORK AV[ , N 11" . %% `%MUNGTON, D. C. _'txltlb A101-7977 4 5 CERTIFICATE OF Distribution to: # J$ S 4 OWNER SUBSTANTIAL ARCHITECT 0 COMPLETION COIED RACTOR 0 AIA DOCUMENT G704 OTHER p PROJECT: Fire Station No.. 14 ARCHITECT: AC Associates (name, address) 96th & Avenue X Lubbock, Texas ARCHITECT'S PROJECT NUMBER: 8748 TO (Owner): Lubbock Fire Dept. 1100 6th Street Lubbock, Texas 79401 L DATE OF ISSUANCE: April 22, 1985 CONTRACTOR: Ed Lampe CONTRACT FOR: Construction J CONTRACT DATE: October 22, 1985 PROJECT OR DESIGNATED PORTION SHALL INCLUDE: Entire Project The Work performed under this Contract has been reviewed and found to be substantially complete. The Date of Substantial i Completion of the Project or portion thereof designated above is hereby established as which is also the date of commencement of applicable warranties required by the Contract Documents, except as stated below. DEFINITION OF DATE OF SUBSTANTIAL COMPLETION The Date of Substantial Completion of the Work or designated portion thereof is the Date certified by the Architect when construction is sufficiently complete, in accordance with the Contract Documents, so the Owner can occupy or utilize the Work or designated portion thereof for the use for which it is intended, as expressed in the Contract Documents. A list of items to be completed or corrected, prepared by JUQXXk{the Architect, is attached hereto. The failure to include any items on such list does not alter the responsibility of t e Contractor to complete all Work' in accordance with the Contract Documents. The date of commencement of warranties for items on the attached list will I be the date of final payment unless otherwise agreed to in writing. AC Associates `��'' / L20�� ARCHITECT BY DATE The Contractor will complete or correct the Work on theinlist of it attached reto withSixty (60) days from the above Date of Substantial Completion. Ed Lampe 41Z-5 1 i CONTRACTOR BY DTE The Owner accepts the Work or designated portion thereof as substantially complete and will assume full possession thereof. at (time) on (date). The City of Lubbock, Texas OWNER BY AT The responsibilities of the Owner and the Contractor for security, maintenance, heat, utilities, damage to the Work and insurance shall be as follows: j (Note—Owner's and Contractor's legal and insurance counsel should determine and review insurance requirements and coverage; Contractor shall secure consent of surety company, it any.) The owner assumes all responsibility for security, maintenance, heat, utilities, damage to the work and insurance. AIA DOCUMENT 0704 • CERTIFICATE OF SUBSTANTIAL COMPLETION APRIL 1978 EDITION • AIAe 0 1978 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 6704 — 1978 i FIRE STATION NO. 14 List of uncompleted items accompanying certificates of substantial completion. 1.) Building name letters are not installed on south elevation. 2.) Storage Room 108: Seal around conduits -where they penetrate ceiling. 3.) Replace water heater flue vent,caps with Breidert Air-X-Hauster type. 4.) Install 100 Amp, 2 pole,, spare switch in panel 5.) Install identifying name plates on panels "A" and "DP". 6.) Install chalkboard in Dining Room.