Loading...
HomeMy WebLinkAboutResolution - 2016-R0198 - Collier Construction Company - 06/09/2016Resolution No.2016-R0198 Item No.5.16 June 9.2016 RESOLUTION BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF LUBBOCK: THAT the City Council of the City of Lubbock does hereby ratify for all intents and purposes the City Manager's execution, for and on behalf of the City of Lubbock. Change Order No. 2 to that certain Contract No.12191 by and between the City of Lubbock and Collier Construction Company of Lubbock.Texas,for Fire Alarm System Replacement at Lubbock Preston Smith International Airport Terminal Building, and related documents. Said Change Order No. 2 is attached hereto and incorporated in this resolution as if fully set forth herein and shall be included in the minutes of the City Council. Passed by the City Council on June 9.2016 • Uu-^ DANIEL M.POPE,MAYOR ATTEST: jds£L^L6 Rebafcca Garza.CitySecretary APPROVED AS TO CONTENT Kelly Campbell.Executive Director of Aviation APPROVED AS TO FORM: tant City Attorney RES.ChgOrd#2-Collier Construction Company 5.2.2016 Contract No: 12191 City of Lubbock Purchasing and Contract Management Change Order Contractor: Collier Construction Change Order No. 002 Contract Title: Fire Ahmm Replacement at LPSIA BID/RFP No. RFP 15-12191-7F Project Number: 92191 "Change Order" means a written order to a Contractor executed by the Owner in accordance with the contract authorizing an addition to, deletion Irmo, or adjustment or revision of the requirements of the contract documents. or an adjustment to the compensation payable to Contractor, or to the time for performance of the contract and completion of the PmjML or a combination thereof, which does not alter the nature of the thing to be constructed and is an integral pan of the project objective. Adjustments to "Estimated Quantities" to a line item in a Unit Price contract do not require a Change Order. All murk that alters the nature of the thine to be constructed or that is not an integral part of the oroiect obiecti a must he let out for public bid Description of change (alteration, deviation, addition, or deletion) caused by conditions encountered during construction not covered by the specifications and drawings of the project (attach additional pages ifnecersary): Revision 1 indicated on the following drawings dated 2/11/2016: FP1-0, FP1-1, FP1-2, FP1-3. FP1-4,FP1-5, FP1-6, FP2-0, FP2-1, FP2-2, FP2-3, FP2-4, FP2-5, FP2-6, FP3-0, FP3-1, FP3-2, FP3-3, FP3-4. 2. Where the Change Order is negotiated, the Change Order must be fully documented and itemized as to casts, including material quantities, material casts. taxes, insurance, employce benefits, other related costs. profit and overhead. Where certain unit prices are contained in the initial cantract, no deviations are allowed in computing negotiated change order costs. ITEMIZED COSTS MUST BE FULLY DOCUMENTED AND ATTACHED TO THIS FORM. ITEM DESCRIPTION AMOUNT A. ORIGINAL CONTRACT VALUE: $ an.5oo 0o B. AMOUNT OF THIS CI4ANGE ORDER:( $ 42.235.47 COST CENTER: ACCOUNT: C. PERCENT OF CONTRACT VALUE THIS CHANGE ORDER (B/A): 6.59 % D. AMOUNT OF PREVIOUS CHANGE ORDERS: $ 18,486.45 E. TOTAL AMOUNT OF ALL CHANGE ORDERS (B+D): $ 60,721.92 F. PERCENT OF CONTRACT OF ALL CHANGE ORDERS (EJA): 7.5N nwnvne 9.47 % G. NEW CONTRACT AMOUNT(A+E): ge dreng,r S T . -70aI17-(, 9a 3. It is mutually agreed that the above dollar amount and the time extension. as applicable, as set forth in this Change Order constitutes full compensation to die Contractor 1'or all costs, expenses and damages to the Contractor, whether direct consequential or othenwise, in anyway incident to. or arising out of or resulting directly or indirectly: fmm the work performed or modified by the Contractor under this Change Order. A ©m (1) CONTR.AC"I'OR Date ' (2)PR JEC' 2CHIlECO1ENGINEER Date I roved as Io Zt t A r 41121 t*MWNER'S REPRESENTATIVE D to 14 N . W to t' � : d ' I�ti, G. c, ✓ 4 6 (5) CAPITAL PROJECTS MANAGER Date 0) 1 HA G A D CON'IRAC'T M.4 1 ER Mil houge Orden over S25.000 require a Can CmtrSheerandthefollowing COY O L B CA A (7) MAYOR Date (8) CITYRE.TARY CC Council Date: June 9, 2016 Agenda Item g: 5.1 Resolution 0 198 M'R-I51Rec 1210121 April 20, 2016 1191 C O L L I E R CONSTRUCTION COMPANY DFW Consulting Julian Rachman 1616 Corporate Court Suite 100 Irving, Texas 75038 Lubbock Preston Smith International Airport Fire Alarm Replacement Project - Change Order #2 Project number: 92191 Mr. Rachman - The Initial project walk through by members of the Lubbock Fire Marshall's Office (LFMO) Identified areas of the terminal building requiring additional fire alarm system devices that were not specified in the original plans and specifications for the project. The cost to Install these additional devices is $42,235.47. The contractor is requesting 45 additional business days to complete this work. Scope of work: Electrical for additional devices $ 23,449.62 Fire alarm for additional devices $ 13,606.14 Supervision $ 2,000.00 Bond premium $ 1,168.50 Dumpster $ SUBTOTAL $ 40,224.26 Contractor markup $ 2,011.21 Subtotal $ 42,235.47 Sales tax ® 8.25% $ - TOTAL S 42,235.47 Qualifications: We will require a time extension of 90 days from the time of receiving a signed change order. Sincerely: Collier Construction Company Scott Collier Conlraclor/Supplier- Job Name - Contract/Work Order/PO Number 1.) Labor and Material to install the 32 Additional Devices as requested. Request: A. 6-Smoke Detector B. 6. Heat Detector C. 5-AV D. 10-Pull Stations E. B-Conveyor Shut Down Modules DIRECT LABOR INSTALL 6 SMOKE DETECTOR: ROUGH/TRIM ( includes removal and reinstall of 2 adjacent devices) MAN HOURS INSTALL B HEAT DETECTOR: ROUGHfrRIM: (Includes removal and reinstall of 2 adjacent devices) MAN HOURS COSTPROPOSAL DENT ELECTRIC UAP Change Order s2 Add Additional Devices 60.00 RATE $5627 60.00 RATE INSTALL 5 AV: ROUGH AND TRIM:(Inlcudas 50.00 RATE removal and reinstall of 2 adjacent devices) MAN HOURS INSTALL 10 PULL STATION: ROUGH/TRIM: (includes removal and reinstall of 2 adjacent units) MAN HOURS INSTALL 8 CONVEYOR SHUTDOWN MODULE: ROUGH/TRIM: Includes removal and reinstall of 2 adjacent units) MAN HOURS $56.27 $56.27 100.00 RATE $5627 80.00 RATE $66.27 $/Hr= Labor Subtotal MATERIAL MATERIAL MATERIALS FOR ADDITIONAL DEVICES: 3/4' PER EMT, 162 AND 142 DEVICES 35 DEVICE S45.D0 PLENUM HATED FIRE ALARM CABLE, 4-SQUARE BOXES, WIREMOLD BOXES AND WIRE MOLD EQUIPMENT Subtotal Sales tax 5% 5% $ 3,370 S S 3.376 $ 2,814 S S 5,627 $ s 4,502 $ $ s 19.695 LABOR SUBTOTAL S 19.695 $ 1.675 $ $ 1,575 MATERIAL SUBTOTAL $ 1,575 s EQUIPMENT RENTAL SUBTOTAL S TOTALDIRECTCOST S 21.270 OVERHEAD MARK-UP 1.063 SUBTOTAL S 22,333 PROFIT MARK-UP 1,117 TOTAL CHANGE AMOUNT 23,449.62 We will require a time extension of 45 work days to perform these changes. These days do not Include the 16 day extension that has already been granted or the E weeks lost in February and March due to work stoppage for change order This price Is based on x_straight time, X_overtime, _shift work, _time and I Exclusfgna 1.) Sales Tax 2.1 Fire Alarm devices, design and Programming 3.1 Painting and Patching Honeywell International Inc. Honeywell Building solutions Building Systems Agreement Proposal Number: E6159-1830465 Proposal Name: ABQ-LPSIA Fire Alarm Add Rev 1 Date: 4/8/2016 Provider: ("Honeywell") Customer. ("Customer') Honeywell International Inc., through its ollicf C nslruoio;; Honeywell Building Solutions business unit O'_ill tiara Nkuco Bl.d. \1 "_(I= A\e.wc L Alhuqueiip;e_ ACN Niczicu 87113 1 ubbo,_I:. I X '0SO4 Contact Person: Scott Collier Phone #: 806-741-1982 Email address: scoff@colliertx.com Work Site Location Name: Lubbock Preston Smite International Airport Work Site Location Address. 5401 NMartin L Sing Blvd, Lubbock, TX 79403 Scope of Work: Honeywell will furnish the engineering for the devices as illustrated in the change order to the shop drawings for installation purposes. It is understood that the AHJ is not requiring any additional documents for a new or change to the fire alarm permit (by others). Furthermore, Honeywell will furnish the fire alarm devices; programming, assistance / supervision of fire device termination (as described below), device checkout, As -Built drawings, and customer / AHJ acceptance testing for die project. Project scope is based on the Lubbock Preston Smith International Airport FPI-0 through FPl-6 & FP2-0 through FP2-4, drawings provided by DFW Consulting Group, Inc. project number 14007 dated 2/11/2016, and this proposal along with the following Inclusions, Qualifications, Assumptions and Clarifications and Exclusions. Additional Fire Alarm System: Provide 8 hours of a state licensed fire alarm technician to assist in terminating the fire alarm devices with electrician contractor as required by AHJ and Texas Administrative Code Title 28. Part 1, Chapter 34, Subchapter F, Rule 34.606, #8. Provide (for installation by others) the following a new Honeywell XLS3000 Fire Alarm System (FAS) including: • (7) Control Modules. • (9) Intelligent Pull Stations. • (7) Heat Detectors. • (5) Ceiling Smoke Detectors. • (4) Strobes. Note: Per spec section 0160 00 — I, 2.1, A. no existing products shall be re -used. 2. Provide technician labor for software load and final checkout with AHJ and electrical contractor. 3. Provide as -built and closeout documentation. 4. Includes state and local approval fees (permits and associated fees by others). 5. Includes Honeywell standard FAS products and a (1) year warranty. 6. Per the General Instructions, Item 20.20.2: TEXAS STATE SALES TAX 20.1 This contract is issued by an organization which qualifies for exemption provisions pursuant to provisions of Article 20.04 of the Texas Limited Sales, Excise and Use Tar Act. 20.2 The Contractor must obtain (provided to Honeywell at NTP) a limited sales, excise and use tax permit which shall enable him to buy the materials to be incorporated into the work without paying the tax at the time of purchase. Period of Performance: The Work shall commence directly after receipt of a fully executed change order and shall add at least 30 calendar days to the contract completion date. tloncyeell Building Systems Agreement (Rev. I I.15) Page I of 6 Qualifications: 1. Change order proposal assumes limited project management involvement until the completion of this project. It is agreed that Honeywell PM will attend project meetings by phone and only one site visit is expected before completion of the project. 2. Electricians must coordinate termination of fire alarm devices and panels with Honeywell. It is required by the Lubbock Fire Marshal's office that a licensed fire alarm technician be onsite while fire alarm devices and panels are installed. 3. All work to be done during regular business hours. 4. Please reference the proposal number above on any subcontract or purchase order. 5. Any contract provided to Honeywell will include all language in this proposal. 6. HONEYWELL WILL NOT PROCEED WITH ANY WORK (Engineering, material ordering, on -site rough in, etc.) WITHOUT A FULLY EXECUTED CONTRACT. 7. WRITTEN DIRECTION WILL BE REQUIRED FOR ANY CHANGES OR VARIATIONS FROM THE CONSTRUCTION DRAWINGS OR SPECIFICATIONS. Additional Clarification: 1. This addition will add 30 calendar days to the Honeywell part of the schedule after the completion of electrical install. 2. A copy of the changes, marked in a different color, will be submitted to the Fire Marshal's office as "As Builts" at the conclusion of the project, as per Lubbock Fire Marshal's Office. 3. Any scope of work changes required by the AH1 and/or Owner that is above and beyond the specifications and drawings will need to be addressed by bulletin and separate proposal. 4. Project includes coordination with other trades. Period of performance is contingent on the timely work of other trades. 5. Contractor will allow sufficient time in the schedule, after electrical installation, to allow for checkout by Honeywell prior to scheduled completion date. 6. AutoCad drawings in the proper version will be required and provided upon notice to proceed, by the Architect or Owner, at no charge to Honeywell. 7. Honeywell reserves the right to negotiate mutually acceptable terms and conditions. Exclusions: 1. Any demo work. (Demo work provided by electrical installer) 2. Any Ethernet wiring. 3. Any third party communications integration. 4. Any work that is not defined in this proposal. 5. Any EF work other than what is listed in the inclusions. 6. Any work associated with fire alarm system in building, under a different contract. 7. Any work associated with the Smoke control system in building. 8. UPS, Surge suppressor and lightning protection. 9. Smoke/Fire Dampers. 10. Any damper(s) of any kind. It. Cutting, patching, painting. 12. Previously damaged ceiling tile. 13. Any additional permitting or fees, payments and performance bonds. 14. Liquidated damages. 15. Any bond(s) 16. Lighting control Intelligent Devices and Control Systems to BMS otter than listed in the inclusions. 17. Power Monitor System Intelligent Devices and Control Units 18. Security, Access system or connection with Security/Access system. 19. Any training associated with National Dust Control Program. 20, OCIP insurance reduction for our installation subcontractors only. (Honeywell is self -insured and will not participate.) 21. Vertical transportation (man -lift). 22. Dumpsters. 23. Participation in composite cleanup crews. Note: Honeywell will provide clean up relating to our work only. Price: THIRTEEN THOUSAND SIX HUNDRED SIX AND 14 /100 ($13,606.14) U.S. Dollars (as it maybe adjusted pursuant to the Agreement, the "Price") ❑ Use Tax is included in the price ® This sale is tax exempt Honeywell Building Systems Agreement (Rev. 11.15) Page 2 of 6 ❑ Sales Tax will be invoiced separately Payment: Upon Customer acceptance of this proposal or contract execution, whichever occurs first, the Customer shall pay Honeywell or percent ( %) of the Price. Such payment shall be used for engineering, drafting, and other mobilization costs reasonably incurred prior to on -site installation. This proposal is valid for 30 days. Proposal Submitted By: Name: Norma Valdez Title: Business Consultant Acceptance: This proposal and the pages attached shall become an Agreement in accordance with Section 13 of the General Terms and Conditions below only upon signature below by an authorized representative of Honeywell and Customer, subject to credit approval by Honeywell. Accepted by: HONE, YWELL INTERNATIONAL INC., CUSTOMER: Collier Construction through its Honeywell Building Solutions business unit Signature: By: Signature: By: Name: Title: Name: Title: Honeywell Building Systems Agreement (Rev. 11-15) Page 3 of 6 General Terms and Conditions I. WORKING FIGURE UnlenolhmevesralN, ill labored smmn miler lhisAgttmml xdl be pnfwn,N d�ringthehours ofg Pg am -a JOpm lord ume Afondry thmmd, Faday,adudm6 fdnd Ml,days Iffmmyrtmon Cmlomvsmunm Hmrywxll b tumid, wyauh labmar smrmaaumd<ofde Mum oft W am -d JO p m local time MmHy Ihmugh F.W. w fedtN lichdays), vd' mxmme m mherwa atmal eapemeommmd drcrcby, wish ac o,whe w anv,nd cans nm anchored in this Ap,anm, shill be MIId so and Fad by CmmnuF 2. TAXES 2.1 Cummrcr agrcmeo pry Ne amawsofmy newer Inv<vd lamm LmxmnenW chagv upon lahm m depoducvoN zhgmws,rile, InsWlv,m. m useofmurpmrng ar mRxve xiuchbmmc eRcrosx oRntlrcdveof IMs Aim If Coming claim wy with Isms do root apply to hanmmem coaxed by this Ayeesm, Cuvome, thanmonds, Hog axth aimomm,pum cmiRmre mmplable a 6:.a,licage rung amhanl,n 1 TauRelmedCeamretiem Cmbmm egcnto aeeeme wY m,mmnn wdbmomde dthuenil esammWe mopervwnro HmcYwdl mlvedb Houyaedl su Ehng order blmdRamue CdeSer n1i90 HonryoWlwllbt ddPakd the salesman FAO btneR<iary 11 Allmopnmay cal dan(u dcfind Mrm)obmndby Cmbmmfexm Nmmxetl In ronnttmn xtth thlzhgeeevml Stull rcmm thepmmrzy of Homyxell,ad Cubmm.thall notdwlgesu,h,nfomadan bagdurdparry xnheul PdornoinrnmmmtofrVagdoongw As,Badheil gimesmnmew,garymfgromad shallmemwntrn in,bmuuon(moN infomntlmsedmdtoaamrby gnarnfempdm inmuhinnrratlable fomk bWudn6 but mtlimndlosonwve supplidbCmmmu Memndm xhdl tbneywdl denim propnnary or conRdmlW and<h»mmiznmprapdenry al thekmr of diubsvelo CmmmerMmukin¢mlabehng thesame'Propnnary. "Cwfdmual", or "Swalive The Cmrom:e shill mmr m a6118mIms Avnmdv coil IvpM m propn<tvy infomadm eefii<M1 (a) evu in tMCmronu s posmam m wv 4mnn Ip de Cmom<r wet to its remim Rnv Hmvvuxll: (bl u mdeomdmM akveloeed by de wrnmded buffs ro a thrad parry Rom IloneJ+sxll or Romwixme.wine wdm,n control. (� is sttelaxd by Cmmmu Nor mnhml,m ro Honryxpll thag the toff Cmbmu agew thst Hone2nwll maY me mnPeaPnnay Infarmgim PwaNnB w the APnmenk and IM1e xod � rind uMtr the APAmnwl. for Prmr rtleves, eve sgd,q data anayus. Pmmmmml purpow, and mho amly ndwe'Wmgenbe cd Mpublldyrelaxd.Nmryx<II maY.tlwnBmdaRea the Term of dos Abrmmml,<ompile and use,andd,zumimt<w vnnyrmm andaggee6med fomk ill dan md,nfommm rtlmedbbmldmgoWimzwan mdrneagy untie ob Wned In cwucMn will th,sApttmnt. The ny,n and obhTyions in thin Secdon J aM1WI zurvive geminmrm or nmimdmofthisAymmmt d. INSIMANCE OBLIGATIONS 0.1lloneywdl shalt, at Its own s,sme, nrrya st maintain In fore, a' all limn from 11, 1,11. dole afeheA,..,.[lbrou[4 Ond cempinlm of the work It.falls. to, imurmm. Il bagmd, hoxever,IMt Iteneyntll lca ,he right to in ma or c,INlnsuee my of the harmame cnxnges IRgd bdnx: (a) Cemmtnivl Clearing Lgii IMunnv le imlude contractual Unruh, pcodu0,/mmplend mendma IiabNry nigh a comhin<d single nMl of USD S2,PWAM per ovurr<mo Such polity rein he avdam on m e,mrmnm form bold (b)1f automobile ert and m the aum,on of the Agrument, Amomabde flabby Insurw<e nigh a minimum cambmd angle limig of USD S'!,PCD,eBP pu occunmco. Cavnage will include ill oxncd, lemed, mm�oned and hiretl axhides (a)W6nets lin61q'All Risk"1'mmny Imurwu,..cludn6 Builder's Rok htmmom for physical damage on, forces, olneh is oswmd in the Agreement (JI kYarkm' Campennllen Imm�nn Cmemge A •Smlmory IIMn antl Conn[e B•Cmpteyxh Liabiliy lmm�nm xid Ilmla of USD SI,OOdAW fer badny injurynch acdtlent ertlbmn. Itnn we0 rill cone gnat eeaxr en M1ufa doff Pnano de mmmmcm,an ofde Agrmmmk Hweywsll will famish ecidame ofwdimurmm emxnPHshe fecal acts MemomWum of lmwmco nfiich is vttalNe eg: hnn„hmmxen.omMlm'mof Allmsumt,ri adin thm5e-rimdxill bawnllmly,mmpamn wtharaingofnolnsthw"A-,XB'byA.M Bnlmequimlmngingagmry No-�eywdl swill endeavor to pondeasM1lrry()0)day nolic<ufunmllmimmnanrm,xalbtM (lalemn Nsha mint dv a self-mi Program a insocmened HaVy"ll will proaidc admuem prmfafOmnnd respoaNliry. S HAZARDOUS St IR4A NCEE MIO LDAND INSAFE WORKING CONBRIOIS SI Cubmmhv cal oSurvd orettneN nobs frommysmme(famdaeinrmmil)of, orris isaevmeof(v)Harudms Std,sanaror Mold tithe, vrbome orwar xithrn thexvlls,loon.«dngs,hevmg vmalaum coil drmWitaning syamc plmnbingoyslmg,mm,me, andothv mmpmrnuofthe sin,ar acidinfuNcare finnan, tgmPmenL m,na6lmsace pipelhl a na Ste,or(b)windfom that hirM must or pmmoro mainuIalm, mnerntntbn, Baexsh or damomn ofHaamdom Substm. ar MoWan m wthrn arch locadnm S.2 Hism"ill m cool ostensible fee Eug gam., mheder mY egepmea m the awn mine, hvm:dry and emgilMan innings and by Cwtmnm, ve appaapaate for Cupomes and the She acpt uspmhcilly pmandd go no mad,d Work Scope Dommrm Sl Bay smh vulmds,vemgiomw madmu, xhdal dmlowd mnm. me closes d by Hmwkwxll er ader< and pond, w maall msduan for the pedingaga flha xmk al Sm,<a. de dsmexry ofdte mnd an shall meaimma cacao brymd Hmeyemll'srmunable scowl cad Hmeyxdl sFdl Moe dr dlj,l to cnwithe ewtkm Smue will the am by bern made mfebY Cuaam<ra: Cuaamei Seeprerntlkm, atCuvamea's seem, Hmawcllslullism h< tight roeerMMnhs Abrtmtrnl ifCunomee by cat fWly rtmdlasd dewvfe imdlbm xi,6inaxey (60}dayz efdsemay. Sa Cmbmer reprvmv thAl Cmlemm M1u me retmd Heuryxxll go drsmaxr, tmpeck Invapgme, idwuy, M ecpmm6le for, prmmt w emdiae Haaudem Subwncn er Mkld u condrmm mvcd fry Haadom Subimn<n m hldd Flanryaadlsbill hammdury,ahbevmn or Itatilly, ell of xfdsh Cunemn ne anpxaica, fin wydamage orcldm xfiether Inoumwwbmxn, mcludne but nN Ilmdd apropmydamage, pvwimllryury,loss of imm�e,mmimil dma, dead,, Ion of me bss efvilue, dvmc hNlh eRen or my speclil. <mmmmnd, pwlbm, aemplary m othn damage. rrDvdes ofxfiedursysh dvnagv mat' beeruud by m athenaisavo,ivud cad dtfe,n in the Work, M xfiolem th pan Ax toaman8 Ram my Invm,lpation, IesanB wdn�s, manibnng elewmg rtmavd, d,peml, aMgemmL aemd,mon, haantammdon, r mpe,smil immy, dead ordtsmein my wayonodarod cad Hmmdom Substmweor Mold tear, replmsmmt, rcbcaum, Ims alum ofbmldmg, or ry,dpmml coil rymems, 6. WARRANT' 6.1 Hmryevdl "Ill sePlme er ropy my product Hwryxxll plewdn undv,hia Agr<ummt has Oils ,xd W the xmnwry p-ad or., (I) Ym became graehionm xodmwilup or m,long,, <mep, in the nawt the rvlure rwlm form Cummv negl,gmn. fr<, Iighm,nD vacua damage, w ve' odor <aum bmmnd dam control of Hamyx:Il Thn rs We is effmin m of the rime "IV mi am gat ohm old, yedmg o g i rive C osi at bepas bme0ad me of the :mdr,aLx4xhevv meant, mddtdlmrr),. wwmw we(I)YmsRv wisbaalasreplaced, flu Hlf=y, an abligoMmade mmm,rg wild hearing, , penjhvxannnsmol airmyeplacemeeLpnmad. mll'S elmlon, of the pplimbl d fttdve Produsb xe,hin de mv(I)Ymr ummnry Period All prodmnrepmrd or aeplxcd,,fmY. ve wmrmlld only fin theamanin6 cad uuxpnd pon,m o(thomgiml orrclll yew xanwypmod 62 ENCMASECPRFSSLYPROVIOEDWSECTION6I,IIONETY'ELLMAKESNOREPRUMTAnONSORIVAR ,%TIES,WIIMERWRFITEN,EXPRESSIMPLIEO,SFATIRORVOROITERNVME, AND HEREBY DISCLAIMS ALL REPRESENTATIONS AND WARRANTIES, INCLUDING BUT NOT LIMITED TO.THE IMPLIED WARRANTIES OF 111ERCIIANTABILITY AND FITNESS FOR PARTINLAR PURPOSE AND ANT AND ALL WARRANTIES REGARDING HAZARDOUS SUBSTANCES OR MOLD. NO EX7fEN510N OF Tit IS WARRANTI' WILL BE BINDING UPON RONETVELL UNLESS SET FORTH IN WRITING AND SIGNED BY HONEMELL'S AUTHORIZED REPRESENTATIVE 1. INDEAINIT' m myemesfC,mangw,nomlimtatioangdm misemdNUT AND HOLD ar wym IEVI VE n mile. TO. CONSU MT HOLDD ATTORNEYS' E Y ' FE TO. CONSULTANTS' AND.ITTORN'EYS' STOPPAGE TNAT rry ANY I\'Al'RESULTS & LIMITATIONOFMARIIITY TO TILE ACREEh1ENT ARISES Mohr BREACII ,noBimn. gems",'] from cad'mon, brn,h o! thu Agrem,mt ar PORECOINC,TO TIIE 1 LLCL INISANDCOS4 BREACH OF THE ThIs Senlm ] shill surviax mNmien or apimwn EVENT WILL HONEYWELL OE LIABLE FOR ORTIM LOSS OR CORRUPTION OF DATA 01 PRICE TO THE EXTENT OROTIIERWISE LIMITATIONS AND Honeywell Building Systems Agreement (Rev. 11-15) Page 4 of 6 o, gagxA I lPbiln bs, alarm, casts (or dle6d negliSmce ar nillful LUDING BUTNOT LIMITED D Win] DELAY OR WORK NISTENCE OF AIOLO OR A Common' eery on. cam,'.. my RISINGOUTOFORREIATED APPLY WHETHER LIABILITY 9. nQISAOI.F.DfIAVS Iloneyxdl dull rot be Fable fordamagn award by deHy or imerrupuov in Smaeus dean or 11, Mod. ..'a radiation', in Nt err, Not , below, N,puie nal, xoA., ,baby w obmn mvenal m emian, mmmaom, or. ens of God Jm G,nna[aofllaardow Subnanmar Alddmaq tNd<nuu bryand Hmeywdl's rmraiublemnlrtl Shoidd ypan treat, Oaemormy Evipmmt be damaged by fire, wall, Iighmm,, emaf God, lilt preunmofllazvdorn SubRuw m Altld thW pamR ar my othu<awe bawd dre mmlfd afllmgxaell, my«pmn m teplaumant shill be peid for by Cwtwnu In da mmt of any two May. more afshlpmmtarpedomuvm Ndl be exrnded by a Mod aqud w the ome Inlbyrusonofrv<h ddaY. and Hmgwdl shill M lotted IO rtmvn boor Cmomt.rd rmwnawe m.,a. ,resod .nAmMl n,.em.. nnm e..a,41- 10. PATENTINMAINITY 10.1 Hm ToncHdWiu mapnu, dN dw,aesnapwm.demy on that my he oriental egernn Cmalmrfarallefd management ofmy United Smlmpmmu mindw the hudwarc ar wlluvemmuf card and Provided by Honeywellwdn Nif Apmntem jibe mwpmm1�.Pro.idedrMt alsail by Nomyxdl he,nndtt. b) ftlswmer&ws Honcy.Nl Imm:drat mlim ilinlex.ndOntiol'maysunchnawl land pmmm¢theHumugo%h.ulc, hrthrougheouurgphmenamelmurmepofelifu chamtl. a the <whemrp,itrinnGmnigNm,anmy elverdn¢ekpan, orwOxvenolDronded and defend zu<h own, rrW e) Cuswmer give Hmrywell all needed mfmmom, ansmwemd adMriry, w Haoepwll's enpane, w enable HmeywdM10 ddmdwda sWl lo.E Hanel. a s nt bra mmrmd or is lame mil', Wimen is Ilkdy m Ore. , Ilmaywell may, at its el¢Ilm am npmu a) a ojew for Cnwmer the all, m mnwue mmg .,h equipmmL b) refit , Not., or ramify d w lhm n is net ordra g, w xbraNara) w hire f 'bll, then e) elm e such egw,NNa and g,m, Col.,, adll Nand m. usdepmiated 10.5In the .of. find award of&mgas u.Noysteb sulkjimeywelxillprylrwhawtid Honryxdlshell nok ho..w<r, be rtspomrble for any edtlemml male wNmun xmtm crosmt. 10.4 THIS SECTION 10 STATES HONEIIVELL'S TOTAL LIABILITY AND C 001ER'S SOLE REMEDY FOR ANY ACTUALOR ALLEGED INFRINGEMENT OF ANT PATENT DY THE HARDWARE MANUFACTURED AND PROVIDED BY HONEYIYELLIIEREUNDER. 11. SOFTYARE I.I(TNSE All ullmov mwded m mmaww wN Nn Apummr ehdllne Mimed and aalwld Thc mduurofrhewfrive rill he mgmed w van v licesue agrmmml xtrh pronnwu hmmnyuu ofDw wRxve to the Wulpmenl lad wdn Nmespdifiuwwn,hdwgtapynb pewaamg wnfidmmllry, andprdribidnIIlrmsfm lo>third W,ry Lonsa ofNrs lyW are Rmdmd for tamputn-bused claimant *jibe type covdby thin Apartment' fupom[r Ndl6e etpened to pant Ilmpvell oum la Ne and txs k, pumosn ofabraming Ne mm�svywlMvo Inverse D. DISPUITRFSn1.IMON \till. Ne n of a,m *fairy <mnmerry or d., awn. out ofor,deld to Ne rm byvlonmonol�g andbr mamrna,<e ed fire and/or in onry donem, No Pmdn earn Alta mY cmlrovn l' w Alto bnxeen Hmon All and Cusmmcr nsm.omafort<bnng In thin Agreemmk ae Nvbmeh Numf,N1116e mWdbyumlrmiw inancm,d vnvq mnduvedro mmedann xkN tM ConnrvcOW lndmtry ArMtnnw Rulnahhe Amdaan Arbitration AssonwYn Any .used mnd<md by Jn mbnnur Nall be finil, mdjmpmom mybe nmrduDvnnwe¢e,dm<a wvF appli[nble lmvin mYmunhnmglunsGnim,Mm/ My<mtmanryordmmarningoulofwmlaldwilermnl4twn,monnonn5, aad'ar mimdan<r of yrsmrm mwnated wN snunry awarr Ne delmuan aL md/w mduvien *frisk of lasuwtevd wN fivahill be rwol'ed in v corn of<ompetnQunsdivron IL ACCEPPANR:OFTIE CDNTRACT This prapmd and Jte papa anmhd doll bmome to Apeemn, upon ....... ain't by I lwnywdl and Cuswmer The error and ow —dome u1 enplemly limited w Nt povuiam hero[ Ndudrng Hoom,no 's Gourd T. and CanNOom method hdew, ndxaNstandinp tmeipt af. or a<bwwfdyryml bY.11onnyxell ofmy pw<hvawder, Rnifimion, or othd dmummr inued by Custamm Any ddibanal ar drRermndme an !wh m rdnnmd In Cmomci s pwduw ordd ue hdeby objwld wily Honeyxdl mdshdl b<deemed a mvnnd dtvndm Wlhne toms and dill rot be apm dray mWnnII ardtt 11, LIISCELLANEDIIF 14.1 he nThrs Apednm, 111.11 do, more Agrwmam berxam Co. nand Hmeywdl I. the Walk rhombd heeds and avparsdes all poor wrowarm,, rryrmmalon p A,.. be. the Pomd related toNe work deunbd II.2 Nwm of Ne Dwndms of Nrs Agmmmt Hill be ramified iltaeQ <M1anpd a„andd by my rvbsmumt Pwdau Order w miler donmcm um Werilly rerued by Cmr*mr Nat edmv to the wbjnt mend of than AGeemmt. Thn Aptemmt my heammded only by xnnm itmumm upredby bath Pmin. 11]Thb AlpnmmtsM1ill be IImxmd by law bwof Ne Snte,.lmre the xn,k is to bepaf red name, am Any prisons pm oflhie Apewdt hdd1ceawjtdmkenprimal under mytanmraIIWmmzdmll bedevoteinow di,andallmmnamngpwvrmm�n onsintebeadid anti nhundo Honeywell and Crmom,. wiw apwthat this Agreement shall be nfamed to replace soh mrickn pwnlam at pan IhnroTnaN a void and nfwreable pa'ision that calm us [Iwem Waide w exprening,M1e Nlmnon lathe smakm prannm HIS Cwwlner mYrol vmpn na nghn wd<lepam its oblraauom wdanhn Agmtmem.In nMlear m pm, xaNmt Ne prior xnnm mmmt ofNweya'dl Ilonry..ell maY amrmr ro nyhl ra rtmve prymenl to ethird pony 15. TF.RRISOFPAMIENT Subject w Hnrywdl'a approval orCwwmara negk prymem morn are an fvlloaf. Pmum,Pat vmm,a-Hwrywall ordlinwieel1. mOmhlyfar nil mvmds cidwered to IN job late or to m oR-dw mange facility and for all lrnmllauamlabor, and semen performed. birth oa and ifth,all nor Cameleer ag,.. pay lilt fallimounu imalcod International, upow al ofaremwme in Ne Infirm spmifed by the Customer. Mvoicn not pdd within Nirry lJO)dayaof Neinwiw lame se prat due and mcmumerm fiom tAnnwice tom to Ne lame of Wynommthe.ware.. pereem(M.)pderand mmmwded ,owl, or thohtghem I'll .,.Ill. allowed BG a. �C lamer andl nw wirhhd4 v mdmgn, a peatee ptanmge rhm m xathhcld ham Cunomd wdn a pnme <muam, If apPllobla Co mmet emal paY ml mvtuge Io Hmoyxdl xaJw Jo dolt dtv Hmq..ell'a s ark m perAlyocmem rmuiremnd, dun on,mmne PaJmml w0m,thirty (aq days aner eubmanwn or. Homm,tD mama, Haneywll may omp ,ale aril Cop., al LL WORN"OMERS 16.1 Unlussolhmssewdinled Aefdlonina nem amrobefumishdmdintdld by others: donne nanng and a<cnwriR all io-line dewms 6lxlWrng bulnol lrmltdwDwvlubR hmdvdvRanfiwplatn,onto Bmev,ne), qpe ad pippmelrnidv indeding Danan formomwSPrnsure and Ind Yantminen, temanatwesew9rS.vmwun breiln; Dauga .loon, ward colamR mmpmm fowGlram, ngpng; pelarl Ila[in8. and ill aNcmwm[ and wad ar1Ae mm,e Auomtic vdu bodin and dampen fwudted by Fbaya'dl ercwhe inWld bY*thers. 16,25emua Nmwymll will p,owde rmdrr this ApemtmasPtdfpllY axdudeProfeubnd unnn xlu<h mnelnuw the Prmmeo(wchnevu,ewmpnemng unlea spmfitally sal fwthw NeSmpeofWmk Cowmair omnawll sporty all Performance and drop enema am Hmeywell„ill follow in Wdo..,%Yak wale, this Apaemem Upafessimd dnipt semcmwmnrfimumo by adnim prof siwml rdvedw ryvcm, maldals. or cgmnmrntnrequired oral. umcee and unifica0ms are Ne rnWmrmliry of.then lonestind eapmn. mdmmgbmrolbmtedroatmmryi fen,hTaoumNel, witYnotrnml' from m mmaradbmy anchor ,Cbreach dofthe ryindemmifyan in thin Sactoo his.mdon Hontywell andrat aIInm and<mplq'<n form uW ayAma any and all elaimk damaaR 16 Thu mdemnlfmaw drill sunivmeamrnmrm ofrhu Aprmm�n fon.haievdrcawn Raihm. in ahn 5duw Id shall be<omnued m,egdm Nor fmiemer mdemnifY and hold haeMrn Hwlrywdl (wen dram and taus mulYng boor HonO',mll', ne.fSnl alms ar xdlfW rdnandun II. DELIVERY Otlirep• ofequipmmr ml oared m NrPomhdnfw be medalled byar web Ncunnelree of llnnrynell Iwl be FOB vI Hongvell's Dnory, wvehona ar o0me sdeeledby Hwq+vell Debwryofvlmpmemapwdon d e fera hnmf aobe inpalled byw mN the annlanu afHouy,vNl ehWl be C I F m site oremulhhan 19. DAMAGE OR LOSS my yswel a sballnd bt liaaw-,it magcw arlmaf wpdpm yand %amon,fim while, do, fruit mn:al6y Ilan, Common wmy vpphubo pnme wnaaar IfNnnam,ampnw wpavmntin (Wlto Howyxell6yfwwmd, avysud, cqurpmau orwRwve rs dana.ed ardeprq�edbymY rwu xbatwmtr, oJnrNm by the (aWlafHanryan �, the Curamn ogees pmmplV to pay or reimburse Honeywell far sail War 19. TERMINATION 19.1 ea C. Ca far cart aweme.cads the mpvd bdmm. Honeywell Building Syslems Agreement (Rev. 11-15) Page 5 of 6 %Vwk in accordww with to Cunomm 19.3 BY Honvyndl Henryxell may tmmtnue sus Ageemml for mote (ineludmp but not Lwm1 m. Cusfams's f duro tomde paymendt vaBeeN hvnn) vOn Ipnngfwtomn xnnm notice of M1smlend b tnmme I(nahm snot (Y) dpz fdbmn¢ mcerpi ofsu[h omm Cmmmn fn46 side thep'. drtn dw. or..he-. Won, core wperfono iss obbesuno, Flongmull now. by notion notice b Cwtumer. mmtmme this ABrevnml ond semi Dom Cwwm P»mem In, Work..led aM der lossesustvn d for muends, roofs, cmiwnmn equipment and machinery. Indedrng but not Gmnm to. revomble owthwd Prafn send applicable dmnagen 26 CIIANCFS INTIIE WORK 50.1 A Chvgv Order is vwnnm orris vpred 6y Cwdwnn and Naneyxell auUbnvng a drmee m the Noh or addusMmd indM1epnce or a [hmge m the sthedWe SO.i Cunomer may request Hmeyndl bubmt prapvAJs fw chmev to the Wwk, mbjttt b vccequme by Ilmvyxvll. If Customs [houses to Prop<d, mdr [hmpef rn tlu Y1'«k usll be authomedby a Change Order Undesoaduntiu speseedly niii in wei ngby Wh patties, d1loneyxdl subnutf a prepmd I--' to such rtqumt but (lmnms [ham. noI b paned Cunomersbill use is Chong, Otdet b oorob«u Me,"] for soy it sell coat r«vned in Prepsvn6 tbepropoml ]D.l Hmeysell maymde axntlm rtqus. m Cusbmonto modtfyarungrttmrnt baudan rite mmptof, mNv dumvry of, informuion Iha duN Hanepvdl bdiwu rill muse v damge to the scope, prim, schdWc, Iwel ofpvfonomce, orodurlies.of.be Apsmms. A,reeirclf will submit is sequmtb Cusbmv widtm sseasonoble lime aaer rmdpt at-, ordhe dixovery at-, infarmaian Yn Honeyuell beheso rill muuaChmgewthesnipe, price, uhMde.Ind of pedotnvn.,wmherfve td ABrtemwog niuryofles beaubmined by NmeyxvU kfine promeOn6 to a<mmdte tverk emepl inan emergonry<ndmg<nn6 bfe«pmpnry,inohich i.e Honeywell sbJlhmm the putMnrylp o0. in lmdwmion, to Prmmt Orarned damage, injwy oc loss Hmryxxll's rcqum rill bulWa mfodtmtian nttmuytoubaantivtmM1c eRm of the chmgs and enYimpsbm Nv Wotk mdudmg mY Chmge in sdtedule arwmnd pnm lflloneyxdl•srequmia.cepbblem['Cusmmv sallimre nChmBo elder conpdmuhnnnrh V[uvemw and HoneytMl<mnoumee on the pmmm ofthv edjmmrnllnthe Ai<e,«rhe Schedule. it drillbe determined pursumuotha Dispute Rvdmion provisions ofdds fN$A Apeentcm AnY[hmttm We pnroonlu ShedWnsulgng frwn such dsem shJl be mhonxM by (Fwrbm Orde Hongnull tha the ti'ork is r.d, for food trope acts send sec r, Conti t U lode such find inspection and issue a<.ptmme umhin Ibsen (3) bounm days Accoplance mill be in a form pw%ided by the bon of Cmtwwr's knowledge, tnfor on and belief, and on dic basis of ( tomei s no.on vivo sod inspection, die \York M1as been fully ceolileW in mcardmce svth dtc Icon.. sed mrdninv of ,, Inds the Work vnumptable doe to m.."Iion. wtlh a.—d! dement afthts AGcentenk uireh non-mmph. is due solely Ip rite fsWt eMiuru, nill. Customer all noofy Nonryudl to u,oli, uitbn We tng foM thr fpedfiereasom foe nomamrytmKi Ctmomer aye. uia filturomvopectonNor fvl...... moernooce.fwum[ap;ance xstivn duee(S)bxum days"I cmomro ftrola.epweeofNe it [tmmm ru agrm dent prnol of bmeaenl uuoftlw Work by [uatams os Onnv Pr wf$ o Ion wn mnd meeplmte nil) commme mcaglmu or6c %York mils tbs Agmm t. To the fullest usmme� shill iMrmwfy and hold Avmlvs Naneyxdl and ru eS nrs and employm from soil agdml vry and ill dorm, damags, 6sus and <spmss, mduGng bon and limiud mummcyi fro, IAv rn my oar Hmryuell from cbimsand rocs SS. QEFINITIOAC smuesnwoflie Agmmse.lb—htor,11 tt Iwih.ng mntmds 223 "Nesmdnw subnmue"mclW.ello(the folbuin&and sy bypeodm odor from vry ofaty fvllowng. ubedvr wwdlY vuurmgormmuf�vwN,mgmnune, mnduom«conuntruvnu mu M1aw, tin illeBedahas'e,wve swoued tohavesetadverseeRm Is ennathdtb,erd es. yafv Sot,w rifeenbromnmf(a)myam amw, hemdew wmmc pallvmn, wntummnh chembil, marsidwmbsmnee hnnN mhvadous ar roar<orvapollumnt ar smonalnsrmtdsaaewfeduil bused uthem-MldmmpI-I'su nod fudwilonhunustood.eseehod ,adwm,ur.f .or ise a,fmmrHbylaro insdatim, polythlonnnea biphenYl(PCaah mdle)any ederdemted or bioloGN muend orierpnism,dhu ha, is Jleeed tohave or u bdicvW to have m adverse eRm on human hedd,habiobiliryofa5ite, or du mvimnmrnl SLi "Afield' memf my rypeee fomtoffwmawbiolopd mamvd Dr v....iuludngnold mildew, mainure, yial and mwhrmms, send my mywtvums.tpar.. KinN, cr by�produns ptwhmad ondewN bymyofdhe lorogoin8, This band. nor rdamaar mymdt ronmtbnf metre by mira Paniw SS.I"Cowed Equipment- meats no equipment eov edby tAa Semms to be Pufwmnd by Honeywell under this Agnomen, pud is bousid to the< gmpment r«fueled in the rcipttme work imp, murhmenm Honeywell Building Systems Agreement (Rev. 11-15) Page 6 of Honeywell, Intl. Confidential 4/20/2016 Customer Project Name: LPSIA Fire Alan Add Collier Construction COMMERCIAL MATERIALS Security/Safety FA Addition I Security/Safety Parts rctrical8lnstermentati LumpSum ont, Equipment and Tc LumpSum Page 1 Proposal # E6159-1830465 QUANTITY USER NET $ EXTENDED CONTROL MODULES 81 40.001 320.00 PULL STATION 101 66.67 666.70 HEAT DETECTOR 6 33.33 199.98 SMOKE DETECTOR 6 40.00 240.00 STROBE ONLY 51 33.331 166.65 EQUIPMENT TOTAL NET PRICE WARRANTY SUBTOTAL NET PRICE SUBCONTRACT/OUTSIDE PURCHASE Outside Engineering Honeywell Fire Services Group (O&M, As•Builis, Submittals) Eta Sub Rentals TOTAL VENDOR NET PRICE TOTAL OUTSIDE PURCHASE HONEYWELL LABOR Project Manager Superintendent, Proj Comb, instrumentation Field Comm Technic Engineer Level 5 Speclist, Project Engineering Consultant, Engineering Software engineer/Pi Technician, software licensed Adminismattve Administrator Contracts Senior Level TOTAL HONEYWELL LABOR MISCELLANEOUS Travel 8 Expense TOTAL MISC TOTAL SELL LPSIA Price Smakoul_REVISED GV 4.8-16 50.00- 'S1,593:33 $500.00 $500.00 $500.00 2016 RATES 16 155.15 $2,482.40 52 135.20 $7,030.40 0 140.25 $0.00 0 155.22 $0.00 4 66.66 S266.64 $9,779.44 S1,733.37 $1,733.37 $13,606.14 CERTIFICATE OF INTERESTED PARTIES FORM 1295 loll Complete Nos. 1- a and 6 it there are interested parties. OFFICE USE ONLY Complete Nos.1, 2. 3. 5, and 6 if there are no interested parties. CERTIFICATION OF FILING Certificate Number: 1 Name of business entity filing form, and the city, state and country of the business entity's place of business. 2016-66220 Collier Construction Company Lubbock, TX United States Date Filed: 06/06/2016 2 Name of governmental entity or state agency that is a parry to the contract for which the form is being filed. City of Lubbock Date Acknowledged: 3 Provide the identification number used by the governmental entity or state agency to track or identity the contract, and provide a description of the services, goods, or other property to be provided under the contract. RFP 15-12191-TF Fire Alarm System Replacement at the Lubbock Preston Smith International Airport Terminal Building Nature of interest 4 Name of Interested Party City, State, Country (place of business) (check applicable) Controlling I Intermediary Collier. Scott Lubbock, TX United States X 5 Checl: only if there is NO Interested Party. ❑ 6 AFFIDAVIT I swear, or affirm, under penalty of perjury, that the above disclosure is true and correct. CAITUN WALKER C°. �S Notary Public. State of texas t�}✓VV\�/ r My Commission Expires January 06, 2018 ,�'''771�� (�� %+C!�.'rl../ILK Signature of authorized agent of contracting business entity AFFIX NOTARY STAMP / SEAL ABOVE (� Sworn to and subscribed before me, by the said V LO-t f 60111'e r , this the ((0-th day of J) n e i , 20 Ila, to certify which, witness my hand and seal of office. t lll,T�D �fi � r 6/7`b%-i Wa /ke.r_ A/er- rid Signature of officer administeringroath Printed name of officer administering oath Title of officer fidministering oath Forms provided by Texas Ethics Commission www.ethics.state.tx.us Version V1.0.1021 CERTIFICATE OF INTERESTED PARTIES FORM 1295 1of1 Complete Nos. 1- 4 and 6 if there are interested parties. Complete Nos. 1, 2, 3, 5, and 6 if there are no interested parties. OFFICE USE ONLY CERTIFICATION OF FILING Certificate Number: 2016-66220 Date Filed: 06/06/2016 Date Acknowledged: 06/06/2016 1 Name of business entity filing form, and the city, state and country of the business entity's place of business. Collier Construction Company Lubbock, TX United States 2 Name of governmental entity or state agency that is a party to the contract for which the form is being filed. City of Lubbock 3 Provide the identification number used by the governmental entity or state agency to track or identify the contract, and provide a description of the services, goods, or other property to be provided under the contract. RFP 15-12191-TF Fire Alarm System Replacement at the Lubbock Preston Smith International Airport Terminal Building 4 Name of Interested Party City, State, Country (Place of business) Nature of interest (check applicable) Controlling I Intermediary Collier, Scott Lubbock, TX United States X 5 Check only if there is NO Interested Party. ❑ 6 AFFIDAVIT I swear, or affirm, under penalty of perjury, that the above disclosure is true and correct. Signature of authorized agent of contracting business entity AFFIX NOTARY STAMP / SEAL ABOVE Sworn to and subscribed before me, by the said , this the day of 20 , to certify which, witness my hand and seal of office. Signature of officer administering oath Printed name of officer administering oath Title of officer administering oath Forms provided by Texas Ethics Commission www.ethics.state.tx.us Version V1.0.1021