Loading...
HomeMy WebLinkAboutResolution - 3248 - Agreement - HDR Engineering Inc - Evaluation, WTP - 11_16_1989Resolution # 3248 November 16, 1989 Item #9 DGV:dw RESOLUTION BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF LUBBOCK: THAT the Mayor of the City of Lubbock BE and is hereby authorized and directed to execute for and on behalf of the City of Lubbock an Agreement by and between the City of Lubbock and HDR Engineering, Inc., for professional engineering services for the Lubbock Water Treatment Plant, attached herewith, which shall be spread upon the minutes of the Council and as spread upon the minutes of this Council shall constitute and be a part of this Resolution as if fully copied herein in detail. Passed by the City Council this 16th day of November 1989. B. C. M6M NN, MAYOR Rane Boyd, ecretary APP D AS TO CONTENT Dr Hawkins, Director of Water U .lities APPROVED AS TO FORM: v Do d G. Vandiver, First Assistan City Attorney AGREEMENT FOR ENGINEERING SERVICES THIS AGREEMENT, between the City of Lubbock, Texas (hereinafter referred to as Owner) and HDR Engineering, Inc., with principal offices at Suite 125, 12700 Hillcrest Road, Dallas, TX 75230- 2096 (hereinafter referred to as Engineer): WITNESSETH: WHEREAS, Owner intends to upgrade its water treatment plant, located at 6001 North Guava Avenue, to ensure that it consistently produces its designed volume of treated drinking water which meets all requirements of the Safe Drinking Water Act considering a 20-year long-range improvement period. WHEREAS, Owner requires certain professional services in connection with the Project (hereinafter referred to as the Services); and, WHEREAS, Engineer is prepared to provide such Services; NOW THEREFORE, in consideration of the promises contained herein, the parties hereto agree as follows: ARTICLE 1 - EFFECTIVE DATE The effective date of this Agreement shall be November 16, 1989. ARTICLE 2 - SERVICES TO BE PERFORMED BY ENGINEER Engineer shall perform the Services described in Attachment A, Scope of Services, which is attached hereto and incorporated by reference as part of this Agreement; and as described in Engineer's proposal dated September 29, 1989 and the Owner's Request for Proposal RFP #10350, all of which are incorporated by reference as part of the Agreement. ARTICLE 3 - COMPENSATION owner shall pay Engineer in accordance with Attachment B, Compensation, which is attached hereto and incorporated by reference as part of this Agreement. ARTICLE 4 - STANDARD OF CARE Engineer shall exercise the same degree of care, skill, and diligence in the performance of the Services as is ordinarily provided by a professional engineer under similar circumstances and Engineer shall, at no cost to Owner, re -perform services which fail to satisfy the foregoing standard of care. ARTICLE 5 - LIMITATIONS OF RESPONSIBILITY Engineer shall not be responsible for actual construction means, methods, techniques, sequences, procedures, or safety precautions and programs used in connection with the Project by construction contractor. Engineer shall assist the Owner in the administering of its construction contracts with any contractor, subcontractor, vendor, or other project participant in order to fulfill contractual or other responsibilities to the Owner or to comply with federal, state, or local laws, ordinances, regulations, rules, codes, orders, criteria, or standards. ARTICLE 6 - OPINIONS OF CONSTRUCTION COST AND CONSTRUCTION SCHEDULE Since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over contractors', subcontractors', or vendors' methods of determining prices, or over competitive bidding or market conditions, Engineer's cost estimates shall be made on the basis of qualification and experience as a professional engineer. Since Engineer has no control over the resources provided by others to meet contract schedules, Engineer's forecast schedules shall be made on the basis of qualification and experience as a professional engineer. Engineer cannot and does not guarantee that proposals, bids or actual project costs will not vary from his cost estimates or that actual schedules will not vary from his forecast schedules. ARTICLE 7 - LIABILITY AND INDEMNIFICATION 7.1 General. Having considered the risks and potential liabilities that may exist during the performance of the Services and in consideration of the promises included herein, owner and Engineer agree to allocate such liabilities in accordance with this Article 7. Words and phrases used in this Article shall be interpreted in accordance with customary insurance industry usage and practice. 7.2 Indemnification. Engineer agrees to defend, indemnify, and hold Owner whole and harmless against all claims for damages, costs, and expenses of persons or property that may solely arise out of, or be occasioned by, or from any negligent act, error, or omission of Engineer, or any agent, servant, or employee of Engineer in the execution or performance of this Contract. 7.3 Defense of Claims. Ir filed in which negligence is Engineer, Engineer agrees tc accepts Engineer's defense, reimburse Engineer on a pro defense. Owner also agrees on a pro rata basis for any in resolution of such claim. the event an action for damages is alleged on the part of Owner and defend Owner. In the event Owner Owner agrees to indemnify and rata basis for all expenses of to indemnify and reimburse Engineer judgment or amount paid by Engineer Such pro rats share shall be based -2- upon a final judicial determination of negligence or, in the absence of such determination, by mutual agreement. 7.4 Employee Claims. Engineer shall indemnify Owner against legal liability for damages arising out of claims by Engineer's employees. Owner shall indemnify Engineer against legal liability for damages arising out of claims by Owner's employees. 7.5 Limitations of Liability. To the fullest extent permitted by law, Engineer's total liability to Owner for any and all injuries, claims, losses, expenses or damages arising out of or in any way related to the Project or this Agreement from any cause or causes including but not limited to Engineer's negligence, errors, omissions, strict liability, breach of contract or breach of warranty shall not exceed the minimum amounts required by Article 10 of this Agreement. 7.6 Other Project Indemnities. Indemnity provisions shall be incorporated into all Project contractual arrangements entered into by Owner and shall protect Owner and Engineer to the same extent. 7.7 Survival. Upon completion of all services, obligations and duties provided for in this Agreement, or in the event of termination of this Agreement for any reason, the terms and conditions of this Article shall survive. ARTICLE 8 - INDEPENDENT CONTRACTOR Engineer undertakes performance of the Services as an independent contractor and shall be wholly responsible for the methods of its own performance and that of its subcontractors, agents and employees. Owner shall have no right to supervise the methods used but Owner shall have the right to observe such performance. Engineer shall work closely with owner in performing Services under this Agreement. ARTICLE 9 - COMPLIANCE WITH LAWS In performance of the Services, Engineer will comply with applicable regulatory requirements including federal, state, and local laws, rules, regulations, orders, codes, criteria and standards. Engineer shall possess the licenses necessary to allow Engineer to perform the Engineering Services. Engineer shall not be responsible for procuring permits, certificates, and licenses required for any construction unless such responsibilities are specifically assigned to Engineer in Attachment A, Scope of Services. -3- ARTICLE 10 - INSURANCE Prior to the time Engineer is entitled to commence any part of the services under this Contract, Engineer shall procure, pay for, and maintain the following insurance written by companies licensed in the State of Texas or meeting surplus lines requirements of Texas law and acceptable to Owner. The insurance shall be evidence by delivery to Owner of one (1) certificate of insurance, executed by the insurer, listing coverage and limits, expiration date and term of policy, and certifying that the insurer is licenses to do business in Texas or meets the surplus lines requirements of Texas law, or (2) a certified copy of each policy, including all endorsements. The insurance requirements shall remain in effect throughout the term of this Contract. A. Comprehensive General Liability Insurance The Engineer shall have Comprehensive General Liability Insurance with limits of $300,000 Bodily Injury and $300,000 Property Damage per occurrence to include: Premises and Operations Explosion and Collapse Hazard Underground Damage Hazard Products and Completed Operations Hazard Contractual Liability Independent Contractors Coverage Personal Injury (with exclusion "c" waived) The Owner is to be named as an additional insured on this policy for this specific job, and copy of the endorsement doing so is to be attached to the Certificate of Insurance. B. Comprehensive Automobile Liability Insurance The Engineer shall have Comprehensive Automobile Liability Insurance with limits of not less than: Bodily Injury $250/$500,000 Property Damage $100,000 to include all owned and non -owned cars including Employers Non -ownership Liability Hired and Non -owned vehicles The Owner is to be named as an additional insured on this policy for this specific job and copy of the endorsement doing so is to be attached to the Certificate of Insurance. C. Worker's Compensation and Employer's Liability insurance As required by State statute covering all employees whether employed by the Engineer or any Subcontractor on the job with Employer's Liability of at least $100,000 limit. -4- D. Professional Liability Insurance (including errors and omissions) with minimum limits of $1,000,000 per claim. Engineer shall furnish owner certificates of insurance which shall include a provision that such insurance shall not be cancelled without at least thirty days written notice to owner. ARTICLE 11 - OWNER'S RESPONSIBILITIES Owner shall be responsible for all matters described in Attachment C, Owner's Responsibilities, which is attached hereto and incorporated by reference as part of this Agreement. ARTICLE 12 - REUSE OF DOCUMENTS All documents, including drawings, specifications, and computer software, prepared by Engineer pursuant to this Agreement are instruments of service in respect to this Project. They are not intended or represented to be suitable for reuse by Owner or others on extensions of this Project or on any other project. Any reuse without written verification or adaptation by Engineer for the specific purpose intended will be at Owner's sole risk and without liability or legal exposure to Engineer. ARTICLE 13 - AMENDMENT, TERMINATION, AND STOP ORDERS This Contract may be altered or amended only by mutual written consent and may be terminated by the Owner at any time by written notice to the Engineer. Upon receipt of such notice, the Engineer shall, unless the notice directs otherwise, immediately discontinue all work in connection with the performance of this Contract and shall proceed to cancel promptly all existing orders insofar as such orders are chargeable to this Contract. The Engineer shall submit a statement showing in detail the work performed under this Contract to the date of termination. The Owner shall then pay the Engineer promptly that proportion of the prescribed fee which applies to the work actually performed under this Contract, less all payments that have been previously made. Thereupon, copies of all completed work accomplished under this Contract shall be delivered to the Owner. The Owner may issue a Stop Work Order to the Engineer at any time. Upon receipt of such order, the Engineer is to discontinue all work under this Contract and cancel all orders pursuant to the Contract, unless the order otherwise directs. If the Owner does not issue a Restart Order within 60 days after receipt by the Engineer of the Stop Work Order, the Engineer shall regard this Contract terminated in accordance with the foregoing provisions. ARTICLE 14 - NONDISCLOSURE OF PROPRIETARY INFORMATION Engineer shall consider all information provided by Owner to be proprietary unless such information is available from public sources. Engineer shall not publish or disclose proprietary information for any purpose other than the performance of the -5- Services without the prior written authorization of Owner or in response to legal process. ARTICLE 15 - NOTICE Any notice, demand, or request required by or made pursuant to this Agreement shall be deemed properly made if personally delivered in writing or deposited in the United State mail, postage prepaid, to the address specified below. To Engineer: HDR Engineering, Inc. Suite 125 12700 Hillcrest Road Dallas, TX 75230-2096 ATTN: William B. Hagood, Vice President To Owner: City of Lubbock P. O. Box 2000 Lubbock, TX 79457 ATTN: Dan A. Hawkins, Director of Water Utilities Nothing contained in this Article shall be construed to restrict the transmission of routine communications between representative of Engineer and Owner. ARTICLE 16 - UNCONTROLLABLE FORCES Neither Owner nor Engineer shall be considered to be in default of this Agreement if delays in or failure of performance shall be due to uncontrollable forces the effect of which, by the exercise of reasonable diligence, the nonperforming party could not avoid. The term "uncontrollable forces" shall mean any event which results in the prevention or delay of performance by a party of its obligations under this Agreement and which is beyond the control of the nonperforming party. It includes, but is not limited to, fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance, sabotage, inability to procure permits, licenses, or authorizations from any state, local, or federal agency or person for any of the supplies, materials, accesses, or services required to be provided by either Owner or Engineer under this Agreement, strikes, work slowdowns or other labor disturbances, and judicial restraint. Neither party shall, however, be excused from performance if nonperformance is due to uncontrollable forces which are removable or remediable and which the nonperforming party could have, with the exercise of reasonable diligence, removed or remedied with reasonable dispatch. The provisions of this Article shall not be interpreted or construed to require Engineer or Owner to prevent, settle, or otherwise avoid a strike, work slowdown, or other labor action. The nonperforming party shall, ME within a reasonable time of being prevented or delayed from performance by an uncontrollable force, give written notice to the other party describing the circumstances and uncontrollable forces preventing continued performance of the obligations of this Agreement. ARTICLE 17 - GOVERNING LAW This Agreement shall be governed by the laws of the State of Texas. Any suit brought to enforce any provision of this Agreement or for construction of any provision thereof shall be brought in Lubbock County. ARTICLE 18 - MISCELLANEOUS 18.1 Nonwaiver. A waiver by either Owner or Engineer of any breach of this Agreement shall not be binding upon the waiving party unless such waiver is in writing. In the event of a written waiver, such a waiver shall not affect the waiving party's rights with respect to any other or further breach. 18.2 Severability. The invalidity, illegality, or unenforceability of any provision of this Agreement, or the occurrence of any event rendering any portion or provision of this Agreement void, shall in no way affect the validity or enforceability of any other portion or provision of the Agreement. Any void provision shall be deemed severed from the Agreement and the balance of the Agreement shall be construed and enforced as if the Agreement did not contain the particular portion or provision held to be void. The parties further agree to reform the Agreement to replace any stricken provision with a valid provision that comes as close as possible to the intent of the stricken provision. The provisions of this section shall not prevent the entire Agreement from being void should a provision which is of the essence of the agreement be determined to be void. ARTICLE 19 - INTEGRATION AND MODIFICATION This Agreement represents the entire and integrated agreement between the Parties and supersedes all prior negotiations, representations, or agreements, either written or oral. This Agreement may be amended only by a written instrument signed by each of the Parties. ARTICLE 20 - SUCCESSORS AND ASSIGNS Owner and engineer each binds itself and its directors, officers, partners, successors, executors, administrators, assigns and legal representatives to the other party to this Agreement and to the partners, successors, executors, administrators, assigns, and legal representatives of such other party, in respect to all covenants, agreements, and obligations of this Agreement. -7- ARTICLE 21 - ASSIGNMENT Neither Owner nor Engineer shall assign, sublet, or transfer any rights under or interest in (including, but without limitation, monies that may become due or monies that are due) this Agreement without the written consent of the other, except to the extent that the effect of this limitation may be restricted by law. Unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under this Agreement. Nothing contained in this paragraph shall prevent Engineer from employing such independent consultants, associates, and subcontractors as he may deem appropriate to assist him in the performance of the Services hereunder. ARTICLE 22 - SUBCONTRACTORS No work herein called for by the Engineers shall be subcontracted to a subcontractor who is not acceptable to the owner or assigned without prior written approval of the Owner. The Engineer shall require subcontracts to conform to the applicable terms of this Contract and include provisions which require subcontractor compliance with Owner Rules. ARTICLE 23 - THIRD PARTY RIGHTS Nothing herein shall be construed to give any rights or benefits to anyone other than Owner and Engineer. IN WITNESS WHEREOF, the parties have executed this Agreement. CITY OF LUBBOCK, TEXAS APt VED AS Ty CONTENT: A L'Fn A. Hawkins, P.E. 'rector Water Utilities APPROVED AS TO FORM: '-- �/ f 16�L' Lkm TUnr'Vandiftf First Assistant City Attorney lA' C V � • i B. C. Mcf4ihn, Mayor At t _ Ra ette Boyd City Secretary HDR ENGINEERING. INC. By: ' Attest- • do William R. Hindman, P.E. Henry nj s, P.E. Senior Vice President Senior Vi P sident ATTACHMENT A TO CONTRACT FOR ENGINEERING SERVICES Owner: City of Lubbock, Texas Project: Engineering services required to research, investigate, evaluate, and recommend process, facility, and maintenance improvements for the City of Lubbock Water Treatment Plant. A DESCRIPTION OF SCOPE OF SERVICES The scope of services for this municipal water treatment plant evaluation project is as follows. Work will not proceed until Owner has authorized Engineer in writing to proceed. I. PROJECT MANAGEMENT, MEETINGS, AND COORDINATION A. Establish project administrative board, consisting of Engineer's project manager and principals of Engineer and major subcontractors. The board will meet at 30, 70, and 90 per cent completion to assess project status and report their findings to the Owner's project director. B. Participate in the following meetings to review progress and exchange ideas and information. 1. Attend meetings in Lubbock with the City Review Committee to review and discuss the project. Prepare meeting minutes and distribute to all attendees. It is anticipated that four (4) meetings will be needed. 2. Conduct meetings at Engineer's office with Engineer's project manager and major subcontractor project managers to coordinate, review, and discuss the project. Prepare meeting minutes and distribute copies to all attendees and to Owner. 3. Attend meetings in Austin with State regulatory agencies to discuss the project. Engineer will be accompanied by City staff. Prepare meeting minutes and distribute to City attendees. 4. Attend briefing sessions in Lubbock to discuss the project. It is anticipated that two (2) briefings will be held with City Council and/or citizen advisory groups or other special groups. C. Prepare monthly status reports summarizing the progress of the work to date and submit to Owner's project director. Each report will update the project schedule. D. Provide coordination for efforts of project team members, including subcontractors, for work developed in this project. E. Provide technical staff for participation in meetings with City Review Committee in Lubbock to discuss project. F. Provide technical staff for participation in meetings with State regulatory agencies in Austin to discuss project. G. Provide informal quality control review throughout the development of project. Conduct formal reviews of draft report before it is submitted to Owner. II. ENGINEERING AND TECHNICAL SERVICES The ENGINEER shall visit the site, consult with senior plant personnel, research available information onpertinent topics, meet with the OWNER's review team, and consult with all regulatory agencies having authority over the OWNER's potable water production operations as necessary to develop reports, recommendations, plans, and cost estimates for the OWNER to use in evaluating its facilities. The ENGINEER shall determine all costs and schedule the phasing of all recommendations for the 20-year plan. Work to be completed by the ENGINEER shall be completed in accordance with Exhibit A-1, Facilities Evaluation Schedule, and include the following: A. Identify and list general problems within the exisitng water treatment facilities: 1. Evaluate plant hydraulics. 2. Investigate needs and determine the benefits of changing and improving operations and maintenance of the existing facilities. 3. Recommend feasible and beneifcial operations and maintenance improvements for the OWNER's consideration. 4. Perform an audit of the water treatment plant staffing. Evaluate job descriptions, pay classifications, number of employees and training needs. 5. Conduct safety survey and review general safety rules. -2- a 6. Evaluate alternative sludge disposal methods and coagulant recycling. 7. Evaluate laboratory facilities, data collection and quality control/quality assurance program. 8. Review plant record keeping system and recommend data collection improvements. B. Evaluate raw and treated water chemical and physical quality: 1. Analyze water quality concerns of OWNER and other affected communities; contact pertinent - environmental and governmental entities as necessary to obtain planning information. 2. Investigate the feasibility of alternative disinfectants, including cost/benefit analyses. 3. Project future conditions, requirements, and improvements necessary for continued compliance. 4. Identify and evaluate feasible water treatment alterantives 5. Evaluate alternative coagulants and coagulation - flocculation facilities. 6. Investigate alternative chloramine formation points. 7. Investigate taste and odor sources and recommend control strategies. 8. Evaluate filter operations. C. Recommend treatment alternatives: 1. Determine what treatment methods, changes, and/or improvements will be necessary to comply with regulatory agency requirements for the 20-year period. 2. Conduct cost effective analysis of each recommended treatment alternative. 3. Determine cost estimates of all recommendations and show how costs and improvements should be phased over the 20-year period. -3- D. Evaluate plant equipment: 1. Evaluate flow control and basin equalization facilities. 2. Evaluate all structures. 3. Determine equipment automization needs. 4. Evaluate clearwell storage capacity. 5. Evaluate energy utilization efficiency of all prime movers and pumps. 6. Perform an energy audit of each facility component (including HVAC systems) and determine improvements and/or replacements to improve efficiencies and/or reduce energy consumption. 7. Determine instrumentation needs for process monitoring, control, and personnel safety. 8. Evaluate all chemical feed equipment and associated facilities. E. ENGINEER shall prepare a comprehensive report for OWNER review which identified methods used for each evaluation performed and all recommendations for improvements to each area evaluated and the overall treatment facility. Each recommendation shall be accompanied by a cost/benefit analysis. Evaluations, investigations, recommendations, and projects identified shall consider the 20-year long-range improvement period. Each evaluation shall be concluded with a recommendation of one or more alternatives to the existing facility components, which would either improve operations or reduce costs over the next 20- year period. Ten (10) copies of the draft report shall be furnished to the OWNER's Project Manager by April 12, 1990. Twenty-five (25) copies of the final report shall be furnished to the OWNER's Project Manager by May 11, 1990. III. SUPPLEMENTAL SERVICES A. At the request of the OWNER, the ENGINEER will provide Supplemental Services upon written agreement between the OWNER and the ENGINEER defining the extent of such Supplemental Services and the amount and manner in which the ENGINEER will be compensated for such Supplemental Services. -4- \- B. Any work requested by the OWNER that is not included in one of the items listed in any other place will be classified as supplemental services. C. Supplemental services shall include, but are not limited to: 1. Additional meetings with the City Review Committee, citizen advisory groups, and/or other special groups to discuss the project. 2. Additional appearances at City Council meetings, public meetings, public hearings, or before special boards. 3. Supplemental engineering work required to meet the requirements of regulatory or funding agencies that become effective subsequent to the date of this agreement. 4. Special consultants or independent professional associates requested or authorized by the owner, including legal, financial, or additional engineering or technical consultants. -5- EXHIBIT A-1 - FACILITIES EVALUATION SCHEDULE a 19W 1990 Oct Nov Dec Jan Feb Mar Establish Planning Base & Project Goals Hydraulics Operation/Maintenance Audit Plant Staffing Safety Survey Sludge Disposal and Coagulant Recycling Laboratory Records Identify Concerns Disinfectants and Alternatives Address Future Requirements Alternative Treatment Alternative Coagulants and Flocculants Alternative Chloramine Feed Points Taste and Odor Filtration Flow Control and Basin Equalization Structures Equipment Control Clearwell Storage Capacity Energy Audit Instrumentation Needs Chemical Feed Equipment Identify 20-year Treatment Needs Evaluate Costs for All Alternatives Phase Improvements Information Program Staff Responsibilities Laboratory Requirements Data Management Management Memorandum City Staff / Team Review Meeting Technical Resource Group Meetir Draft Report Review Final Report ATTACHMENT B TO CONTRACT FOR ENGINEERING SERVICES Owner: City of Lubbock, Texas Project: Engineering services required to research, investigate, evaluate, and recommend process, facility, and maintenance improvements for the City of Lubbock Water Treatment Plant. COMPENSATION For the services covered by this contract, the Owner agrees to pay the Engineer as follows: A. For project management meetings and coordination and the engineering and technical services to include identification of general problems within the existing facilities, evaluation of raw and treated water chemical and physical quality, recommending treatment alternatives and overall improvements necessary, evaluation of plant structures and equipment, recommending -structural and equipment improvements necessary, and all meetings, an hourly billing fee for Engineer's personnel services as listed in this paragraph. Subcontract personnel services shall be reimbursable expenses and are to be billed at cost. The maximum billed for these Engineer's personnel services shall not exceed $127,500, without further written authorization. In addition, Engineers and subcontractors reimbursable expenses shall be billed at cost. Billing for reimbursable expenses are estimated to be $37,500. The fee schedule for the Engineer's personnel services are specified in paragraph C. B. For supplemental services, an hourly fee for Engineers' personnel as listed in paragraph C plus reimbursable expenses and subcontract billing at cost to Engineer. Each item of supplemental services shall be established before the work is started. The amount billed for each item of supplemental services shall not exceed the amount established for it without further authorization. Additional amounts for supplemental services may be authorized, if necessary, as the work progresses. C. Hourly fees listed herein for Engineer's personnel services will apply until June 1, 1990 and shall be changed annually on January 1st for the upcoming twelve (12) month period. -4 Classification Project Principal Project Manager Sr. Engineer Project Engineer, P.E. Project Technician Staff Engineer Clerical -Drafter Hourly Billing Rate Range $100 $145 $100 - $150 $60 - $90 $45 $50 - $55 $25 - $35 D. The following expenses are reimbursable: 1. Travel, --subsistence, and incidental costs. 2. Use of motor vehicles on a monthly rental basis for assigned vehicles and on a current mileage basis or rental cost basis for vehicles used for short periods. 3. Telegraph costs, long distance telephone costs and project "onsite" telephone costs. 4. Reproduction of reports, drawings, and specifications. 5. Postage and shipping charges for project -related materials. 6. Computer time charges including program use charges. 7. Rental charges for use of equipment. 8. Cost of acquiring any other materials or services specifically for and applicable to only this project. E. The Engineer agrees to use its best efforts to perform the services as defined in Attachment A within the billing limits stated above. F. Monthly payments shall be made to the Engineer by the Owner based on the Engineer's statement. For hourly fee items, the statement shall be itemized to indicate the amount of work performed and the associated reimbursable expenses and subcontract costs. -2- P7 G. The uncontested amount of each statement shall be due and payable upon receipt by the Owner. Carrying charges of 1-1/2 percent per month from the billing date, shall be due for accounts which are not paid within 60 days after the billing date. H. It is understood and agreed that the maximum billings of each of the above items are based on the start of the services being authorized not later than November 23, 1989. If start of services is not authorized by date given, it is understood and agreed that the upper billing limit will be adjusted accordingly by a supplement to this Agreement. I. That the Engineer shall start the performance of the services within ten days of receipt of notice to proceed. J. That the Engineer shall keep records on the basis of generally accepted accounting practice of costs and expenses and which records shall be available to inspection at reasonable times. -3- s ATTACHMENT C TO CONTRACT FOR ENGINEERING SERVICES Owner: City of Lubbock, Texas Project: Engineering services required to research, investigate, evaluate, and recommend process, facility, and maintenance improvements for the City of Lubbock Water Treatment Plant. OWNER'S RESPONSIBILITIES The Owner will furnish, as required by the work and not at the expense of the Engineer, the following items: 1. All maps, drawings, reports, records, audits, annual reports, and other data that are available in the files of the Owner and which may be useful in the work involved under this contract. 2. Access to public and private property when required in performance of the Engineer's services. 3. Office desk space for the Engineer's personnel during preliminary investigations. 4. The services of at least one of the Owner's employees or staff who has the right of entry to, and who has knowledge of, the existing facilities to aid Engineer in conduct of field reviews of existing facilities. 5. Property, boundary, easement, right-of-way, and utility surveys and property descriptions. 6. Full information regarding requirements for the PROJECT. 7. Access to the facility and to all available information concerning the facility. 8. A Project Manager fully acquainted with the PROJECT who has authority to approve changes in the PROJECT, render decisions promptly, and furnish information expeditiously.