HomeMy WebLinkAboutResolution - 052578B - Operating Assistance Grant Contract - DOT - Urban Mass Transportation - 05_25_1978I) KJ:yb RESOLUTION
RESOLUTION AUTHORIZING THE FILING OF AN APPLICATION WITH THE
DEPARTMENT OF TRANSPORTATION, UNITED STATES OF AMERICA, FOR
GRANTS UNDER THE URBAN MASS TRANSPORTATION ACT OF 1964, AS AMEND
ED, FOR AMENDMENTS TO THE GRANTS FOR FY 1974-75 AND FY 1975-76.
WHEREAS, the Secretary of Transportation is authorized to make grants for
mass transportation projects;
WHEREAS, the contract for financial assistance will impose certain obligation
upon the applicant, including the provision by it of the local share of project costs;
WHEREAS, it is required by the U. S. Department of Transportation in accord
with the provisions of Title VI of the Civil Rights Act of 1964, that in connection
with the filing of an application for assistance under the Urban Mass Transportation
Act of 1964, as Amended, the applicant give an assurance that it will comply with
Title VI of the Civil Rights Act of 1964 and the U. S. Department of Transportation
requirements thereunder; and
WHEREAS, it is the goal of the Applicant that minority business enterprise be
utilized to the fullest extent possible in connection with this project, and that de-
finitive procedures shall be established and administered to insure that minority
businesses shall have the maximum feasible opportunity to compete for contracts
when procuring construction contracts, supplies, equipment contracts, or con-
sultant and other services; NOW THEREFORE:
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF LUBBOCK:
1. THAT the MAYOR is authorized to execute and file applications on behalf of
the City of Lubbock with the U. S. Department of Transportation, for amendments
to the original grants to aid in the financing of operating assistance projects pur-
suant to Section 5 of the Urban Mass Transportation Act of 1964, as amended, for
the fiscal years 1974-75 and 1915-76.
2. THAT the MAYOR is authorized to execute and file with such ,applications
an assurance or any other document required by the U. S. Department of Trans-
portation effectuating the purposes of Title VI of the Civil Rights Act of 1964.
3. THAT JOHN L. WILSON, Transit Coordinator, is authorized to furnish
such additional information as the U. S. Department of Transportation may require
in connection with the applications or the project.
4. THAT the MAYOR is authorized to set forth and execute affirmative
minority business policies in connection with the project's procurement needs.
KJ:yb
5. THAT the MAYOR is authorized to execute grant contract agreements on
behalf of the City of Lubbock with the U. S. Department of Transportation for aid
in the financing of the operating assitance projects.
Passed by the City Council this 25th day of May 1978.
DIRK WEST, MAYOR
ATTEST:,.
Treva Phillips, City?e-cre tary- Treasurer
APPROVED AS TO FORM:
• • enter,�r ' • -
,. FOR AMENDMENTS ONLY
URBAN MASS TRANSPORTATION
OPERATING ASSISTANCE GRANT CONTRACT
SECTION 5
PART I
Project No. TX-05-4021
Amendment No. 01
The parties hereto agree that the Urban Mass Transportation Operating
Assistance Grant Contract entered into on May 26, 1977 is amended
as set forth below:
NOTE: If more than one amendment has been done, dates of all
contracts should be noted.
GRANTEE: City of Lubbock
MASS TRANSPORTATION SYSTEM: Lubbock Transit System
PROJECT TIME PERIOD: October 1, 1975, to September 30, 1976
ELIGIBLE PROJECT OPERATING EXPENSES: (Total Eligible expenses -
including amendment and original
$578,542
FEDERAL SHARE: (Total Federal Share - including amendment and original)
$214,627
DATE OF 13(c) CERTIFICATION LETTER FROM THE DEPARTMENT OF LABOR:
Original 13(c) and date of 13(c) for the amendment.
October 5, 1976
July 25, 1978
The additional increment of Federal funds is $ 52,570
Pag�, e 1 of 7 --__
A
THIS CULT:-:ICT, effective on the date belowspecified, by i:nd
►�, tctLen the United States of Amevica (the "Government") and i':e
Grantee named on page ;one of this Grant Contract, WITH ESSETH:
In consideration of the mutual covenants, promises and
representations herein, the parties hereto agree as 'follows:
Sec. 1. Purpose. of Contract - The purpose of this Contract is
to provide for the undertaken of an urban mass transportation
operating assistance project ?the "Project") with Government financial
assistance to the Grantee in the form of an -operating assistance
grant (the "Grant"), under the Urban Mass Transportation Act of 1964,
as amended (the "Act )and to state the terms and conditions upon
which such assistance will be provided and the manner in which the
Project will be undertaken.
Sec. 2. The Grant Contract - This Contract consists of this
Part I entitled Urban Mass Transportation Operating Assistance Grant
Contract, and Part II, entitled Urban Mass Transportation Grant
Contract, Terms and Conditions, Form UMTA F 5B, dated 5/8/78
Sec. 3. The 'Project - The -Project involves the continued or
improved operation of the mass transit system named on page one
of this Grant Contract for the time period described on page one.
The Grantee agrees to provide for the continued or improved
operation of the system, substantially as described in its Application,
filed with and approved by. the Government, incorporated in this
Agreement by reference, and in accordance with the terms and conditions
of this Contract.
Sec. 4. The -Grant - In order to assist the Grantee in financing
the project operating expenses that are eligible for Federal financial
assistance (herein called "Eligible Project Operating Expenses"), such
Eligible Project Operating Expenses being estimated to be the the
amount appearing.on page one of this Grant Contract, the Government
will make a Grant in ah'amount not to exceed 50% of the Eligible Project
Operating Expenses, as determined by the Department of Transportation
(DOT) upon completion of the Project,*or in the amount designated as
Federal Share on page one of this Grant Contract, whichever is the
lesser. Federal funds made available under this Section will be from
available Section 5 apportioned funds.
For purposes of this Grant Contract "Eligible Project Operating
Expenses" must be in conformance with the requirements of Federal
Management Circular 74-4 (FMC 74-4), "Cost Principles Applicable to
Grants and Contracts with State and Local Governments" and with any
guidelines or regulations issued by UMTA.
5/8/78
page two
-_-es teat it will provid2 fron sources other than
i ru^ds nr ' Lvv;►ues, from the upEv i ion of ;public mass trz::,slyurtat►on
<<<,a, an amount sufficient, toge ier with the Grant, to assure
of Eligible Project, Operating Expenses in an amount equal to
the dr:vllnt provided under this Grant Contract. The Grantee further
agrees that no refund or reduction of the amount provided under this
Grant'Contract will be made so as to lower the local share below
the Federal share at any time, unless there is at the same time a
refund to the Government -of an equal amount.
Sec. 5. Maintenance of Effort - The Grantee agrees that the
Federal financial assistance provided pursuant to this Grant Contract
will be supplementary to and not in substitution for the average
amount of State and local government funds and other transit revenues,
as defined in guidelines or regulations issued by UMTA, expended
on the operation of mass transportation service in the area involved
for the two fiscal years -preceding the fiscal year for which the
funds are made available.
Any failure on the part of the Grantee to comply with this
Section shall be deemed a violation of the terms of this Contract,
and the Government may in its discretion take either or both of the
following actions: (a) terminate all of the financial assistance
provided pursuant to this Grant -Contract; and (b) require the Grantee
to return to the Government any financial assistance provided pursuant
to this Grant Contract.
Sec. 6. Use of Project Funds - The Grantee agrees that the
Federal financia assistance provided under this Grant Contract shall
be applied to the Eligible.. Project Operating Expenses incurred -
in the provision of mass transportation service within the urbanized
area served by the Grantee as described in the Application with
respect to the Project time period described on page one of this
Grant Contract. If, during such period, any Federal financial assistance
provided pursuant to this Grant Contract is not so applied, the
Grantee shall immediately notify the Government.
The Grantee. shall keep satisfactory records in the manner described
in Part II of this Grant Contract with regard to the use of Federal
financial assistance provided pursuant to this Grant Contract and shall
submit upon request such information as the Government may require
in order to assure compliance with this Section.
Sec. 7. Labor Protection - The Grantee agrees to undertake, carry out,
and complete the Project under the terms and conditions determined by
the Secretary of Labor to be fair and equitable to protect the interests
of employees affected by the Project and meeting the requirements of
Section 13(c) of the Act.
5/8/78 page three
These terms and conditions are specified in the letter of
certification to the Government from the Department of Labor on the
date indicated on page one of this Grant Contract, which letter
is incorporated into this Grant Contract by reference.
Sec. S. Special Condition - The Grantee agrees and assures that
the rates charged elderly and handicapped persons during nonpeak
hours for transportation util-izing.or involving the facilities and
equipment financed pursuant to this Grant Contract will not exceed
one-half of the rates generally applicable to other persons at peak
hours, whether the operation of such facilities and equipment is by
the applicant or is by another entity under lease or otherwise.
Sec. II. Offer and Acceptance
A. 'Execution of Contract - This Contract may be simultaneously
executed in several counterparts, each of which shall be considered to
-be an original having identical legal effect.
B. Offer - When dated and signed by the Government, this instrument
shall constitute an offer which should be accepted by the Grantee
by execution within sixty (60) days of such date. -The Government may with-
draw any offer not accepted within the above sixty-day period. Upon
acceptance of the offer the effective date of the Contract shall be the
date on which this offer was executed by the Government.
page four
5/8/78
t1h s c„-ar t- ._ OCT 2 5 1978
r•: i of `-- --_ _ 19
TITLE: REGIONAL DIRECTOR
C. Acceptance - The Grantee does hereby ratify and adopt all
statements, representations, warranties, covenants, and agreements
contained in the Application and supporting materials submitted by it,
and does hereby accept the Government's offer and agrees to all of the
terms and conditions thereof.
Executed this 19 day of � r Z�v , i 9 0
SEAL
ATTEST: BY
ATTEST: TITLE: Mavr)y
D. Certification of Grantee's Attorney
I, mn V4,-,acting as Attorney for the Grantee
do hereby certify that I have examined this Grant Contract and the
proceedings taken by the Grantee relating thereto, and find that the
acceptance of the Government'-s offer by the Grantee has been duly
authorized by the Grantee's action dated Q-3i-'Js' (a copy of
which has been submitted to UMTA) and that the execution of this
Contract is in all respects due and proper and in accordance with
applicable State and local law and further that, in my opinion,
said Grant constitutes a legal and binding obligation of the Grantee
in accordance with the terms thereof. I further certify that to
the best of my knowledge neither.has any law been passed nor is
there any litigation pending or threatened which might affect the
performance of the Project in accordance with t e terms of this
Contract. _
71ppr �S_bi b form:
page five
518I78
ttorney
Form u4m 5B
5/S/78
UNITE) STATES OF A4MCA
DEPARI'M3U OF TRANSPORTATION
URBAN MASS TRANSPORTATION ADMINISTRATION
1WASHI14GMN, D.C. 20590
A of T*4NS0% �
4
r �a
0
L. Z
G V�
Ziff�i:.
O SrATES �
URBAN MASS TRANSPORTATION GRAM CONTRACT
PART II
'PERMS AND CONDITIONS
for Projects under Section 3, 5, 6, or 9 of
the Urban Tdass Transportation Act of 1964,
as Amended and for Mass Transportation Projects
under the Federal Aid Highway Act of 1973
Y• U N Y V *;
Section 101.
Definitions...........................................
1
Section 102.
Acecnplishment oftheProject .........................
2
(a)
General Requirements. ...... ..................
2
(b)
Pursuant to Federal, State and Local Law........
2
(c)
Funds of the Grantee..*........
(d)
Submission of Proceedings, Contract and Other
Documents .....................................
2
(e)
Changed Conditions Affecting Performance........
2
(f)
No Government Obligations to Third Parties ......
3
(g)
Land Acquisition Policy .........................
3
Section 103.
The Project Budget ................... ....... ....
3
Section 104.
Accounting Records ....................................
3
(a)
Project Accounts ................................
3
(b)
Funds Received or Made Available for the
Project.. ....................................
3
(c)
Allowable Costs.. ..............................
4
(d)
Documentation of Project Costs ..................
4
(e)
Checks, Orders and vouchers .....................
4
(f)
Audit and Inspection ............................
5
Section 105.
Requisitions and Payments .... .........................
5
(a)
Request for Payment by the Grantee..............
5
(b)
Payment by the Government .......................
5
(c)
Disallowed Costs ................................
6
(d)
Letter of Credit... .............................
6
Section 106.
Right of Government to Termi.nate........ ...........
6
Section 107
Project Settlement and Close -Out ......................
7
Section 108
Contracts of the Grantee......... �
.. ..............
7
Section 109
Restrictions, Prohibitions, Controls, and Labor
Provisions.... .....................................
7
(a)
Equal Employment Opportunity ....................
7
(b)
Minority Business Enterprise .. ........ .........
8
(c)
Construction Contracts - Nondiscrimination......
9
(d)
Construction Contracts - Specifications ........:1.1.
(e)
Construction Contracts - Notice.. ............17
(f)
Title VI - Civil Rights Act of 1964.............18
(g)
Competitive Bidding ........................
18
(h)
Ethics... .......... ..........................
18
(i)
Interest of Members of or Delegates to
Congress.. .... ......... ..................1
9
(j)
Labor ProvisionsConstruction..................1
9
Section 110. Construction Contracts ................................ 26
(a) Changes in Construction Contracts ............... 26
(b) Contract Security...... 26
(c) Insurance During Construction ................... 26
(d) Signs ........................................... 2.6
(e) Liquidated Damages Provision .................... 26
(f) Provisions of Construction Contracts............ 26
(g) Actual Work by Contractor... ........ ....... 21
(h) Force Account ................................... 27
i.
Section 1" . Environmental and Resource Protection Requirements.:.... 27
(a) Compliance with Environmental Standards..,.... ... 27
(b) Aix Pollution ..................................... 27
(c) Use of Public Lands........ ..... .............. . 27
(d) Historic Preservation ............................. 27
Section 112. Patent Rights.. ............................. ...8
Section 113. Rights in Data ......................................... 30
Section 114. Cargo Preference - Use of United.
Vessels.... 31
Section 115. Charter and School Bus Operations ....................... 32
(a) Charter Bus.. ............................ .. 32
(b) School Bus...... ....................... ...... 32
Section 116.. Compliance with Elderly and Handicapped Regulations..... 32
Section 117. Flood Hazards ........................................... 32
Section 118. Miscellaneous ....................... ... ........... 33
(a) Bonus or Commission...... ......... ..... .. 33
(b) State or Territorial Law ........................... 33,
(c) Records ........................................... 33
(d) How Contract Affected by Provisions Held Invalid.. 33.
ii
• �' • 'Ji ILlI •1 'Y' • 9Y` •
GRANT CONTRACT -
PART II -- TERMS ARID CONDITIONS
Constituting part of the GRANT CONTRACT providing for
Federal financial assistance under the provisions of
the Urban Mass Transportation Act of 1964,-as amended,
and/or the Federal -Aid Highway Act of 1973.
Section 101. Definitions. As used in this Grant Contract:
"Application" means the written application for Federal financial
assistance for the Project, together with all explantory, support-
ing, or supplementary documents, heretofore filed with UMPA by
or on behalf of the Grantee, which has been accepted and approved
by UMTA.
"Approval, Authorization, Concurrence, Waiver" means a conscious,
written act by an authorized official of the Government granting
perr_ti.ssion to the Grantee to perform an act pursuant to this
Contract which could not be perforned without such permission.
An approval, authorization, concurrence, or waiver permitting
the performance of a specific act shall not consititute per-
mission to perform similar acts unless such broad permission
is clearly stated. Oral permission or interpretations shall
have no legal force or effect.
"External Operating Manual" means the most recent UMTA manual of
that title, which presents information about the UMM programs,
application processing procedures, and guidance for administering
approved projects.
"Government" means the United States of America, or its cognizant
Agency, the Department of Transportation (DOT) or its Agency,
the Urban Mass Transportation Administration (UMM) used hereafter
interchangeably.
"Grantee" means the recipient, including any sub -grantee, of Federal
funds from UMTA.
"Mass Transportation Service" means general or special transporta-
tion service provided to the public (but not school bus, charter
or sightseeing service) on a regular and continuing basis in the
urban area described in the application. Project equipment and
facilities may be used for incidental charter or sightseeing
1
service when not needed for mass transportation service operations.
Project facilities or equipment may not be used for the provision
of service under contract either for the exclusive use of students
going to and fran school or for which an individual fare is not
age
"ProjectDescription" means the most recently dated statement, signed _
by UMSA, setting forth all of the activities to be performed by
the Grantee with regard to its urban mass transportation program
pursuant to this Contract which are,not otherwise specifically provided
for in this Contract.
"Secretary" means Secretary of the Department of Transportation or
his duly authorized designee.
Section 102. Accomplishment of the Project.
(a) General Requirements. The Grantee shall commence, carry on, and
canplete the Project with all practicable dispatch, in a sound,
economical, and efficient manner, and inaccordancewith the
provisions hereof, the Application, and all applicable laws.
(b) Pursuant to Federal, State, and Local Law. In performance of its
obligations pursuant to this,Contract, the -Grantee and its con-
tractors shall comply with all applicable provisions of Federal,
State, and local law. All limits or standards set forth in this
Contract to be observed in the performance of the Project are
minimian requirements, and shall not affect the application of
more restrictive State or local standards for the performance of
the Project; Provided, however, in its procurement actions
pursuant to the Project, the Grantee shall not give any pre-
ference to or discriminate against goods and services produced
or manufactured in any country, State, or other geographical
area.
(c) Funds of the Grantee. The Grantee shall initiate and prosecute to
cmpletion all proceedings necessary to enable the Grantee to
provide its share of the Project costs at or prior to the time
that such funds are needed to meet Project costs.
(d) Submission of Proceedings, Contract and Other Documents. The Grantee
shall submit to the Government such data, reports, records, contract
and other documents relating to the Project as the Government may
require. The Grantee shall retain intact, for three years following
Project close-out, all Project documents, financial records, and
supporting documents.
(eY Changed Conditions Affecting Performance. The Grantee shall imTedi
ately notify ufrA of any change in conditions or local law, or of
any other event, which may significantly affect its ability to
perform the Project in accordance with the provisions of this Contract.
2
(f) No Government Obligations to Third Parties. The Government shall
not be subject to any obligations or liabilities by contractors
of the Grantee or their subcontractors or any other person not
a party to this Contract in connection with the performance of
this Project pursuant to the provisions of this Contract without
its specific consent and notwithstanding its concurrence in or
approval of the award of any Contract or subcontract or the s6li-
citation thereof.
(g) band Acquisition Policy. Any acquisition of land for use in connection
with the Project must confona to the policies and procedures set
forth in the External Operating Manual and the Land Acquisition and
Relocation Assistance Procedures Manual.
Section 103. The Project Budget. A Project Budget shall be prepared
and maintamied the Grantee. The Grantee shall carry out the Project
and shall incur obligations against and make disbursements of Project
Funds only in conformity with the latest approved budget for the Project.
The budget may be revised franm time to time in accordance with the
External Operating Manual or other written guidance fxcn LEA.
Section 104. Accounting Records.
(a) Project Accounts. The Grantee shall establish and maintain as a
separate set of accounts, or as an integral part of its current
accounting scheme, accounts for the Project as described in the
External Operating Manual unless UMT.A specifically authorizes the
use of some other accounting procedures.
(b) Funds Received or Made Available for the Project. The Grantee shall
appropriately record in the Project A==t, and deposit in a bank
or trust company which is a member of the Federal Deposit insurance
Corporation, all Grant payments received by it from the Government
Pursuant to this Contract and all other funds provided for, accruing
to, or otherwise received on account of the Project, which Govern-
ment payments and other funds are herein collectively referred to
as "Project Funds," in accordance with the provisions of Office of
Management and Budget Circular A-102, Revised. The Grantee shall
require the depositories of Project Funds to secure continuously
and fully all Project Funds in excess of the amounts insured under
Federal plans, or under State plans which have been approved for
the deposit of Project Funds by DOT, by the deposit or setting aside
of collateral of the types and -in the manner as described by State
law for the security of public funds, or approved by [A+M. A
separate bank account shall be required when drawdcwns are made by
letter of credit.
3
(c) Allowable Costs. Expenditures made by the Grantee shall be reim-
sable as allowable costs to the extent -they meet all of the
requirements set forth below.. They must:
(1) be made in conformance with the Project Description and
the Project Budget and all other provisions of this Contract;
(2) be necessary in order to accomplish the Project;
(3) be reasonable in amount for the goods or services purchased;
(4) be actual net costs to the Grantee ( i.e., the price paid
minus any refunds, rebates, or other items of value received by
the Grantee which have the effect of reducing the cost actually
incurred;)
(5) be incurred (and be for work performed) after the date
of this Contract, unless specific authorization from T21TA to the
contrary is received;
(6) be in conformance with the standards for allcwability of
costs set forth in Federal Management Circular 74-4 WIC 74-4) and
with anv cauideli.nes or regulations issued by UCA:
(7) be satisfactorily documented; and
(8) be treated uniformly and consistently under accounting
principles and procedures approved or prescribed by UMM for the
Grantee; and those approved or prescribed by the Grantee for its
contractors
(d) Documentation of Project Costs. All costs charged to the Project,
including any approved services contributed by the'Grantee or others,
shall be supported by properly executed payrolls, time records,
invoices, contracts, or vouchers evidencing in detail the nature
and propriety of the charges.
(e) Checks, Orders, and Vouchers. Any check or order dram by the
Grantee with respect to any item which is or will be chargeable
against the Project Account will be drawn only in accordance
with a properly signed voucher then on file in the office of
the Grantee stating in proper detail the purpose for which such
check or order is drawn. All checks, payrolls, invoices, contracts,
vouchers, orders, or other accounting documents pertaining in whole
or in part to the Project shall be clearly identified, readily
accessible, and, to the extentfeasible, kept separate and apart
from all other such documents.
4
(f) Audit and Inspection. The Grantee shall permit, and shall require
its contractors to permit, the Government to inspect all work,
materials, payrolls, and other data and records with regard to
the Project. MIA also may require the Grantee to furnish at any
time prior to close-out of the Project, audit reports prepared
according to generally accepted accounting principles.
section 105. Requisitions and Payments.
(a) Requests for Payment by the Grantee. The Grantee may make requests
for payment of the Federal share of allowable costs, and UMZA shall
honor such requests in the manner Set forth in this section. in order
to receive Federal grant payments, the Grantee must:
(1) completely execute and submit to MUA (1) !tandard Form
270 in accordance with the instructions contained therein, a (2) UMA
F 1340.6 ('IMM Project Budget Line Item Data Entry") ;
(2) submit to UM an explanation of the purposes for which
costs have been incurred to date or are reasonably expected to be
incurred within the requisition period (not more than 30 days
after the date of submission);
(3) demonstrate or certify that it has supplied local funds
adequate, when omibined with the -Federal payments, to cover all
costs to be incurred to the end of the requisition period; and
(4) have submitted all financial and progress reports
currently required by this Contract.
(b) Payment by the Government. Upon receipt of the requisition form
and the accompany g=6rnati on in satisfactory form, the Govern-
ment shall process the requisition if the Grantee is complying
with its obligations pursuant to the Contract, has satisfied LAM
of its need for the Federal funds requested during the requisition
period, and is making adequate progress towards the timely com-
pletion of the Project. If all of these circumstances are found
to exist, the Government shall reimburse apparent allowable costs
incurred (or to be incurred during the requisition period) by the
Grantee up to the maximann amount of the Federal grant payable
through the fiscal year in which the requisition is submitted as
stated in the Project Budget. However, reimbursement of any cost
pursuant to this section shall not constitute a final determination
by the Government of the allowability of such cost and shall not
constitute a waiver of any violation of the terms of this Contract
ccmmitted by the Grantee. The Government will make a final deter-
mination as to allowability only after final audit of the Project
has been conducted.
F7
In the event that UHM determines that the Grantee is riot currently
eligible to receive any or all of the Federal funds requested, it
shall promptly notify the Grantee stating the reasons for such
determination.
(c) Disallowed Costs. In determining the amount of the Grant, UMM
will exclude all Project costs incurred by the Grantee prior to _
the date of this Contract, or prior to the date of the approved
budget for the Project, whichever is earlier; any costs incurred
by the Grantee which are not provided for in the latest approved
budget for the Project; and any costs attributable to goods or services
received under a contract or other arrangement which has not been
concurred in or approved in writing by LWA. Exceptions to the above
statement on disallowed cost are provided in tim External Operating
Manual or in written guidance form tBUA.
(d) Letter of Credit. In the event that a letter of credit is issued
to the -Grantee, the following terms and conditions are
applicable:
(1) the Grantee shall initiate cash drawdowns only when actually
needed for Project disbursements.
(2) the Grantee shall report its cash disbursements and balances
in a timely manner as required by the Government.
(3) the Grantee shall provide for effective control and account-
ability for all Project funds in accordance with requirements and
procedures issued by the Government for use of the letter of credit.
(4) the Grantee shall impose on its subgrantees all the require-
ments of Section 105 (d) (1) (2) and (3) above as applicable.
(5) should the Grantee fail to adhere to the requirements of
Section 105 (d) (1) (2) (3) and (4) above, the Government may
revoke the unobligated"portion of the letter of credit.
(6) Sections 105 (a) (b) and (c) above remain effective to
the extent that they do not conflict with the provisions of
section 105(d)•
Section 106. RI ht of Goverrnnent to Terminate.. upon written notice to
the Grantee, the Government reserves the right to suspend or terminate
all or part of the financial assistance herein provided for when the
Grantee is, or has been, in violation of the terms of this Contract or
when UMTA determines that the purposes of the Act would not be adequately
served by continuation of Federal financial assistance to the Project.
Any failure to make progress or other violation of the Contract which
significantly endangers substantial performance of the Project within
Cl
a reasonable time shall be deemed to be a violation of the terms of
this Contract. Termination of any part of the grant will not invalidate
obligations properly incurred by the Grantee and concurred in by FAWA
prior to the date of termination, to the extent they are noncancellable.
The acceptance of a renittanee by the Government of any or all Project
Funds previously received by the Grantee or the closing out of Federal
financial participation in the Project shall not constitute a waiver of
any claim which the Government may otherwise have arising out of this
Contract.
Section 107. Project Settlement and ,Close-out. Upon receipt of notice
of successful completion of the Project or upon termination by UIM,
UMM shall perform a final audit of the Project to determine the allow -
ability of costs incurred, and shall make settlement of the Federal grant
described in Part I of this Contract. If UM M has made payments to the
Grantee in excess of the total amount of such Federal grant, the Grantee
shall promptly remit such excess to UHM. The Project close -cut occurs
when IAA notifies the Grantee and forwards the final grant payment or when
an appropriate refund of Federal grant funds has been received fran the
Grantee and acknowledged by LEA. Close -gout shall not invalidate any
continuing obligations imposed on the Grantee by this Contract or
contained in the final notification or acknowledgement from UMIA. The
Standard Form 269 will also be submitted at this time and signed by
the Chief Financial Officer and .the Project Manaaer, as specifie,3
the External Operating Manual.
Section 108. Contracts of the Grantee. The Grantee shall not execute
any lease, pledge, mortgage, lien, or other contract touching or
affecting Project facilities or equipment, nor shall it obligate itself
in any other manner, with any third party with respect to the Project,
unless such lease, pledge, mortgage, lien, contract, or other obli-
gation is expressly authorized in writing by DOT; nor shall the Grantee,
by any act or omission of any kind, impair its continuing control over
the use of Project facilities or equipment during the useful life thereof
as determined by DOT.
Section 109. Restrictions, Prohibitions, Controls, and Labor Provisions.
(a) fa4aj Empl!42ent Opportunity. In connection with the carrying out
of the Project, the Grantee shall not discriminate against any
employee or applicant for employment because of race, color, reli-
gion, sex, or national origin. The Grantee shall take affirmative
action to ensure that applicants are employed, and that employees
are treated during employment, without regard to their race, color,
religion, sex, or national origin. Such action shall include, but
not be limited to, the following: employment, upgrading, demotion
or transfer, recruitment or recruitment advertising, layoff or
7
termination; rates of pay or other forms of caripensation; and
selection for training, including apprenticeship. The Grantee
shall insert the foregoing provision (modified only to. show
the particular contractual relationship) in all of its contracts
in connection with the development or operation of the Project,
except contracts for standard'camwercial supplies or raw materials
and construction contracts subject to the provisions of Section 109
(c) of this Contract, and shall require all such contractors to
insert a similar provision in all subcontracts, except sub-
oontracts for standard canrnrical supplies or raw materials.
If the Grantee has submitted, and the Government has approved,
an equal employment opportunity program that the Grantee agrees
to carry out, such program is incorporated into this Contract
by reference. Such program shall be treated as a contractual
obligation; and failure to carry out the terms of that equal
employment opportunity program shall be treated as a violation of
this Contract. Upon notification to the Grantee of its failure
to carry out the approved program, the Gover.Tent will impose
such remedies as it may deem appropriate, which remedies may
include termination of the Contract as provided in Section 106 of
this Contract or other measures that may affect the ability of the
Grantee to obtain future financial assistance under the Urban
Mass Transportation Act of 1964, as amended, or the Federal -Aid
Highway Act of 1973:
(b) Minority Business Enterprise. In connection with the performance
of this Contract the Grantee will provide for full and fair utilization
of minority business enterprises and will use its best efforts to
ensure that minority business enterprises shall have an equitable
opportunity to cmpete for contract and subcontract work under
this Contract.
If as -a condition of assistance the Grantee has submitted, and the
Government has approved, -a minority business enterprise affirmative
action program that the Grantee agrees to carry out, such program
is incorporated into this Contract by reference. Such program
shall be treated as a contractual obligation and failure to carry
out the terms of that approved minority business enterprise action
program shall be treated as a violation of this Contract. Upon
notification to the Grantee of its failure to carry out the approved
program the Govenment will impose such remedies as it may deem
appropriate, which remedies may include termination of the Contract
as provided in Section 106 of this Contract or other measures that
may affect the ability of the Grantee to obtain future financial
assistance under the Urban Mass Transportation Act of 1964, as
amended, or the Federal -Aid Highway Act of 1973.
N
(c) Construction Contracts - Nondiscrimination. Grantee hereby agrees
that it will incorporate or cause to be incorporated into any
contract for construction work, or modification thereof, as defined
in the Regulations of the Secretary of Labor at 41 CFR Chapter 60,
which is paid for in whole or in part with funds obtained from the
Federal: Government or borrowed on the credit of the Federal Govern-
ment pursuant to a grant, -contract, loan, insurance, or guarantee,
or undertaken pursuant to any Federal program inMlving such grant,
contract, loan, insurance, or guarantee, the following equal
opportunity clause:
"During the performance of this Contract, the contractor agrees
as follows:
1(1) The contractor will not discriminate against any employee
or applicant for employment because of race, color, religion, sex,
or national origin. The contractor will take affirmative action to
ensure that applicants are employed, and that employees are
treated during employment without regard to their race, color,
religion, sex, or national origin. Such action shall include,
but not be limited to the following: Employment, upgrading, demotion,
or transfer; recruitment or recruitment advertising; layoff or
termination; rates of pay or other'fonns of compensation; and
selection for training, including apprenticeship. The contractor
agrees to post in conspicuous places, available to employees and
applicants for employment, notices to be provided setting forth
the provisions of this nondiscrimination clause.
1(2) The contractor will, in all solicitations or advertise-
ments for employees placed by or on behalf of the contract, state
that all qualified applicants will receive consideration for employ-
ment without regard to race, color, religion, sex, or national origin.
1(3) The contractor will I send to each labor union or repre-
sentative of workers with which he has a collective bargaining
agreement or other contract or understanding, a notice to be
provided advising the said labor union or workers' representatives
of the contractor's commitments under this section, and shall
post copies of the notice in conspicuous places available to
employees and applicants for employment.
1(4) Zane contractor will comply with all provisions of
Executive Order 11246 of September 24, 1965, as amended, and
of the rules, regulations, and relevant orders of the Secretary
of Labor.
9
1(5) The contractor will furnish all information and reports
required by Executive Order 11246 of September 24, 1965, as aawz ded,
and by rules, regulations, and orders of the Secretary of Labor,
or pursuant thereto, and will permit access to his books,
records, and accounts by the administering agency and the
Secretary of Labor for purposes of investigation to ascertain
ampliance with such rules, regulations, and orders.
1(6) In the event of the contractor's noncompliance with
the non-discrimination clauses of this Contract or with any of
the said rules, regulations or orders, this Contract may be
cancelled, terminated, or suspended in whole or in part and
the contractor may be declared ineligible for further Government
contracts or federally assisted construction contracts in accordance
with procedures authorized in Executive Order 11246 of September 24,
1965, as amended, and such other sanctions may be imposed and remedies
invoked as provided in Executive Order 11246 of September 24, 1965, as
amended, or by rule, regulation, or order of the Secretary of
Labor, or as otherwise provided by law.
'(7) The contractor will include the portion of the sentence
immediately preceding paragraph (1) and the provisions of paragraphs
(1) through (7) in every subcontract or purchase order unless
exempted by rules, regulations, or orders of the Secretary of
Labor issued pursuant to Section 204 of Executive Order 11246
of September 24, 1965, as amended, so that such provisions shall
be binding upon each subcontractor or vendor. The contractor
will take such action with respect to any subcontract or purchase
order as the administering agency may direct as a means of enforcing
such provisions, including sanctions for noncompliance; Provided,
however, That in the event a contractor becomes involved in, or
is threatened with; litigation wi-Vi a su'^contractor or ven,Ior as a
result of such direction by the administering agency, the contractor
may request the United States to enter into such litigation to
protect the interests of the United States
'The Grantee further agrees that it will be bound by the above
equal opportunity clause with respect to'its own employment practices
when it participates in federally assisted construction work; Provided
That if the Grantee so participating is a State or local government,
the aboveequalopportunity clause is not applicable to any agency,
instrumentality or subdivision of such government which does not
participate in work on or under the Contract.
"The Grantee agrees that it will assist and cooperate actively
with the administering agency and the Secretary of Labor in obtaining
the compliance of contractors and subconstractors with the equal
opportunity clause and the rules, regulations, and relevant orders
of the Secretary of Labor, that it will furnish the administering
agency and the Secretary of Labor such information as they may
require for the supervision of such compliance, and that it will
10
otherwise assist the administering agency in the discharge of the
agency's primary responsibility for securing compliance.
'The Grantee further agrees that it will refrain from
entering into any contract or contract modification subject to
Executive Order 11246 of September 24, 1965, as amended, with
a contractor debarred fran, or who has not demonstrated
eligibility for Government contracts and federally assisted
construction contracts pursuant to the Executive Order and will
carry out such sanctions and penalties for violation of the equal
opportunity clause as may be imposed upon contractors and
subcontractors by the administering agency or the Secretary of
Labor pursuant to Part 1I, Subpart D of the Executive Order. In
addition, the Grantee agrees that if it fails or refuses to comply
with these undertakings, the administering agency may take any
or all of the following actions: Cancel, terminate, or suspend
in whole or in part this Grant (contract, loan, insurance, guarantee);
refrain from extending any further assistance to the Grantee
under the program with respect to which the failure or refund occurred
until satisfactory assurance of future compliance has been received
fran such Grantee; and refer the case to the Department of Justice
for appropriate legal proceedings."
(d) Construction Contracts - Specifications. r3rantee hereby agrees
that it will incorporate or cause to be incorporated into any contract
for construction work, cr modification thereof, the specifications set
forth below in all Federal and federally assisted construction contracts
in excess of $10,000 to be performed in geographical areas designated by
the Director, Office of Federal Contract Compliance Programs of the
Department of Labor pursuant to the Regulations of the Secretary of
Labor at 41 CTR Section 60-4.6 and in construction subcontracts in excess
of $10, 000 necessary in whole or in part to the performance of nonconstruction
Federal contracts and subcontracts covered under Executive Order 11246:
STAIMARD FEDERAL EQUAL E PLOY MU OPPOMVINITY CONSTRUCTION CONTRACT
SPECIFICATIONS:
1. As used in these specifications;
a. "Covered area" means the geographical area described in
the solicitation from which this Contract resulted;
b. "Director" means Director, Office of Federal Contract
Compliance Programs, United States Department of Labor, or
any person to khan the Director delegates authority;
c. "Employer identification number" means the Federal Social
Security number used on the Employer's Quarterly Federal Tax
?return, U.S. Treasury Department Form 941.
1].
d. "Minority" includes:
(i) Black (all persons having origins inanyof the Black
African racial groups not of Hispanic origin);
(ii) Hispanic (all persons of :4exican, Puerto Rican, Cuban,
Central or South American or other Spanish Culture or origin,
regardless of race); -
(iii) Asian and Pacific Islander (all persons having origins
in any of the original peoples of the Far East, Southeast
Asia, the Indian Subcontinent, or the Pacific Island) and
(iv) American Indian or Alaskan Native (all persons having
origins in any of the original peoples of North America
and maintaining identifiable tribal affiliations through
membership and participation or amity identification).
2. Whenever the contractor, or any subcontractor at any tier,
subcontracts a portion of the work`involvi.nq any Construction trade,
it shall physically include in each subcontract in access of S10,000
the provisions of these specifications and the Notice which contains
the applicable goals for minority and female participation and which
is set forth in the solicitations from. which this Contract resulted.
3. If the contractor is participating (pursuant to 41 CFR 60-4.5) in
a Hometown Plan approved by the U.S. Department.of Labor in the covered
area either individually or through an association, its affirmative
action obligations on all work in the Plan area (including goals
and timetableW shall be in accordance with that Plan for those trades
which have unions participating in the Plan. Contractors must be
able to demonstrate their participation in and compliance with the
provisions of any such Hometown Plan. Each contractor or subcontractor
participating in an approved Plan is individually required to ca mly
with its obligations under the EEO clause, and to make a good faith
effort to achieve each goal under the Plan in each trade in which it
has employees. The overall good faith performance by other contractors
or subcontractors toward a goal in an approved Plan does not excuse
any covered contractor's or subcontractor's failure to take good
.faith efforts to achieve the Plan goals and timeahles.
4. The contractor shall implement the specific affirmative action
standards provided in paragraphs 7a through p of these specifications.
The goals set forth in the solicitation from which this Contract
resulted are expressed as percentages of the total hours of e ploy-
ment and training of minority and female utilization the contractor
should reasonably be able to achieve in each construction trade in
which it has employees in the covered area The contractor is expected
to make substantially uniform progress toward its goal in each craft
during the period specified.
5. Neither the provisions of any collective bargaining agreement, nor
the failure by a union with,whcm the contractor has a collective
baragaining agreement, to refer either minorities or women shall
excuse the contractor's obligationsunder these snecifications,Executive
Order 11246, or the regulations promulgated pursuant thereto.
12
6. In order for the nonworking training hours of apprentices and
trainees to be counted in rbeting the goals, such apprentices and
trainees mast be employed by the contractor during the training period,
and the contractor must have made a ccomItment to employ the
apprentices and trainees at the completion of their training, subject
to the availability of employment opportunities. Trainees must be
trained pursuant to training programs approved by the U.S. Department
of Labor.
7. The contractor shall take specific affirmative actions to ensure
equal employment opportunity. The evaluation of the contractor's
co,lpliance with these specifications shall be based urn its effort
to achieve maximum results from its actions. T'he contractor shall
document these efforts fully, and shall implement affirmative action
steps at least as extensive as the following:
a. Ensure and maintain a working environment free of harassment,
intimidation, and coercion at all sites, and in all facilities
at which the contractor's eaployees are assigned to work. The
contractor, where possible,will assign two or more wrmen to each
construction project. The contractor shall specifically ensure
that all foremen, superintendents, and other on -site supervisory
personnel are aware of and carry out the contractor's obligation
to maintain such a working environment, with specific attention
to minority or female individuals working at such sites or in
such facilities.
b. Establish and maintain a current list of minority and female
recruitment sources, provide written notification to minority and
female recruitment sources and to community organizations when
the contractor or its unions have employment opportunities
available, and maintain a record of the organizations' responses.
c. Maintain a current file of the names, addresses and telephone
numbers of each minority and female off -the -street applicant
and minority or female referral fran a union, a recruitrent
source or cartcwnity organization and of what action was taken
with respect to each such individual. If such individual was
sent to the union hiring hall for referral and was not referred
back to the contractor by the union or, if referred, not employed
by the contractor, this shall be documented in the file with
the reason therefor, along with whatever additional actions
the contractor may have taken.
d. Provide immediate written notification to the Director when
the union or unions with which the contractor has a collective
bargaining agreement has not referred to the contractor a
minority person or woman sent by the contractor, or when the
contractor has other information that the union referral process
has impeded the contractor's efforts to meet its obligations.
e. Develop on-the-job training opportunities and/or participate
in training programs for the area which expressly include minorities
and women, including upgrading programs and apprenticeship and
trainee programs relevant to the contractor's employment needs
especially those programs funded or approved by the Department of
Labor. The contractor shall provide notice of these programs
to tim sources canpiled under 7b above.
13
f. Dissermnate the contractor's: EEO policy by providing notice
of the 'policy to unions and training programs and requesting
their cooperation in assisting the contractor in meeting its
EEO obligations; by including it in any policy :manual and
collective bargaining agreement: by publicizing it in the
company newspaper, annual report, etc.; by specific revie#
of the policy with all management personnel: and with all minority
and female employees at least once a year; and by posting
the company EEO policy on bulletin boards accessible to all
employees at each location where construction work is perrfo= ed..
g. Review, at least annually, the company's EEO policy and
affi= ative action obligations under these specifications with
all employees having any responsibility for hiring, assignment,
layoff, temnination or other employment decisions including
specific review of these items with onsite supervisory personnel
such as Superintendents, General Foreman, etc., prior to the
initiation of construction work at any job site. A written
record shall be made and mnaintained identifying the time and
place of these meetings, persons attending, subject matter
discussed, and disposition of the subject matter.
h. Disseminate the contractor's EEO policy externally by
including it in any advertising in the neuas media, specifically
including minority and female news media, and providing
written notification to and discussing the contractor's EEO
policy with other contractors and subcontractors with Behan
the contractor does or anticipates doing business.
i. Direct its recruitment efforts, both oral and written, to
minority, female and community organizations, to schools
with minority and female students and to minority and female
recruitment and training organizations serving the contractor's
recruitmentarea and e=_ loyment needs. Not later than one month
prior to the date for the acceptance of applications for apprentice-
ship or other training by any recruitment source, the contractor
shall send written notification to organizations such as the
above, describing the openings, screening procedures, and tests
to be used in the selection process.
j. Encourage present minority and female employees to recruit
other minority persons and women and, where reasonable, provide
after school, summer and vacation employment to minority and
female youth both on the site and in other areas of a contractor's
workforce.
k. Validate all tests and other selection requirements where
there is an obligation to-do so under 41 CFR Part 60-3.
1. Conduct, at least annually, an inventory and evaluation at
least of all minority and female personnel for =cmational
opportunities and enccarage these employees to seek or to prepare
for, through acpropriatF training, etc., such opportunities.
ra. Ensure that seniority practices, job classifications, work
assignments and other personnel practices, do not have a discrimi-
natory effect by continually monitoring all personnel and
14
employment related activities to ensure that the EIM policy
and the contractor's obligations under these specifications
are being carried out.
n. Ensure that all facilities and company activities are
nonsegregated except that separate or single -user toilet and
necessary changing facilities shall be provided to assure privacy
betoe-en the sexes.
o. Doc2ament and maintain a record of all solicitations of
offers for subcontracts .from minority and female construction
contractors and suppliers, including circulation of solicitations
to minority and female contractor associations and other business
associations.
p. Conduct a review, at least annually, of all supervisors'
adherence to and performance under the contractor's EZ:)
policies and affinmtive action obligations.
8. Contractors are encouraged to participate in voluntary associations
which assist in fulfilling one or more of their affirmative action
obligations (7a through p). The efforts of a contractor association,
joint contractor -union, contractor-camimity, or other similar group
of which the contractor is a :member and participant, may be asserted
as fulfilling any one or acre of its obligations under 7a through
of these SLaecifications provided that the contractor actively
partici-pates in the grow, makes every effort to assure that the
group has a ;positive impact on the eployment of minorities and
women in the industry, ensures that the concrete benefits of the
program are reflected in the contractor's minority and female workforce
participation, maces a good faith effort to meet its individual goals
and timetables, and can provide access to documentation which dencnstrates
the effectiveness of actions taken on behalf of the contractor. The
obligation to cxamaly, ha4ever, is the contractor's and failure of
such a group to fulfill an obligation shall not be a defense for the
contractor's nonccapliance.
9. A single goal for minorities and a separate single goal for wcmm
have been established. The contractor, however, is required to provide
ea
ual employment opportunity and to take affi native action for all
minority groups, both male and fe^ale, and all waxen, both minority
and non -minority. Consequently, the contractor may be in violation
of the Executive Order if a particular group is employed in a
substantially disparate manner (for example, even though the contractor
has achieved its goals for women generally, the contractor may be
in violation of the Executive order if a specific minority group
of women is underutilized).
15
10. The contractor shall not use the goals and timetables or
affirmative action standards to discriminate against any, person
because of race, color, religion, sex, or national origin.
11. The contractor shall not enter into any subcontract with any
person or firm debarred fram Government contracts pursuant to
Executive Order 11246.
12. The contractor shall carry out such sanctions and penalties
for violation of these specifications and of the Equal Opportunity
Clause, including suspension, termination and cancellation of existing
subcontracts as may be imposed or ordered pursuant to Executive
Order 11246, as amended, and its implementing regulations by the
Office of Federal Contract Compliance Programs. Any contractor who
fails to carry out such sanctions and penalties shall be in
violation of these specifications and Executive Order 11246, as
amended.
13. The contractor, in fulfulling its obligations under these
specifications, shall implement specific affirmative action steps,
at least as extensive as those standards prescribed in paragraph 7
of these specifications, so as to achieve maximm, results fran its
efforts to ensure equal employment opportunity. If the contractor
fails to cmply with the requirements of the Executive Order, the.
implementing regulations, or these specifications, the Director
shall proceed in accordance with 41 CFR 60-4.8.
14. The contractor shall designate a responsible official to monitor
all employment related activity to ensure that the ocpany EEO policy.
is being carried out, to submit reports relating to the provisions
hereof as may be required by the Government and to keep records.
Records shall at least include for each employee the name, address,
telephone numbers,construction trade, union affiliation if any,
employee identification number when assigned, social security number,
race, sex status (e.g., mechanic , apprentice, trainee, helper, or
laborer), dates of changes in status, hours worked per week in the
indicated trade, rate of pay, and locations at which the work was
performed. Records shall be maintained in an easily understandable
and retrievable fors.; however, to the degree that existing records
satisfy this requirement, contractors shall not be required to
maintain separate records.
15. Nothing herein provided shall be construed as a lirdtation
upon the application of other laws which establish different standards
of ccarpliance or upon the application of requirements for the hiring
of local or other area residents (e.g., those under the Public Works
Employment Act of 1977 and the Campn ity Development Block Grant
Program.)
16
(e) Construction Contracts - Notice. Grantee hereby agrees that it will
incorporate or cause to be incorporated into any contract which is paid
for in whole or in part with funds obtained fram the Federal Government
or borrowed on the credit of the Federal Government pursuant to a grant,
contract, loans, insurance, or guarantee, or undertaken pursuant to
any Federal program involving such grant, contract, loan, insurance,
or guarantee, the following requirement that the notice set forth below
shall be included in, and shall be a part of, all solicitions for offers
and bids on all Federal and federally assisted construction contracts
or subcontracts in excess of $10,000 to be nerformed in aeozrranhical areas
designated by the Director, Office of Federal Contract Compliance
Programs of the Department of Labor at 41 CFR Section 60-4.6:
NOTICE OF REWIMMU FUR AFFIRO= ACTION TO ENSURE EQUAL EMP7IJY''MU:
1. The Offeror's or Bidder's attention is called to the "Equal
Opportunity Clause" and the "Standard Federal Equal Employment
Opportunity Construction Contract Specifications" set forth herein.
2. The goals and timetables for minority and female participation,
expressed in percentage terms for the contractor's aggregate tiark-
force in each trade on all construction work in the covered area,
are as follows:
Timetables Goals for minority s lor e
participation for participation in
each trade each trade
Insert goals for Insert goals for
each year. each year.
These goals are applicable to all the contractor's construction
work (whether or not it is Federal or federally assisted) per-
formed in the covered area.
The contractor's conpliance with the Executive Order and the
regulations in 41 CFR Part 60-4 shall be based on its imple-
mentation of the Equal Opportunity Clause, specific affirmative
action obligations required by the specifications set forth in
41 CFR 60-4.3(a), and its efforts to meet the goals established
for the geographical area where the contract resulting fran this
solicitation is to be performed. The hours of minority and
female employment and training must be substantially uniform
throughout the length of the contract, and in each trade, and
the contractor shall make a good faith effort to eploy
minorities and women evenly on each of its projects. Tim
transfer of minority or female employees or tra=ees from
contractor to contractor or from project to project for the sole
purpose of meeting the contractor's goals shall be a violation of
the contract, the Executive Order and the regulations in
41 CFR Part 60-4. Compliance with the goals will be measured
against the total work hours performed.
17
3. The contractor shall provide written notification to the Director
of the Office of Federal Contract Compliance, Programs within 10
working days of award of any construction subcontract in excess
$10000 at any tier for construction work under the contract
resulting from this solicitation. The notification shall list
the name, address and telephone number of the subcontractor;.
employer identification number estimated dollar.amount of the
subcontract;estimated starting and completion dates of the sub-
contract; and the geographical area in which the contract -is to
be performed.
4. As used in this Notice, and in the contract resulting from this
solicitation, the "covered area" is (insert description of the
geographical areas where the contract is; to be performed giving
the State, county and city, if any).
(f) Title VI - Civil Rights Act Iof 1964. The Grantee will comply with
all the requirements imposed by Title VI of the Civil Rights Act
of 1964 (78 Stat. 252), the Regulations of DOT issued thereunder
(CFR Title 49, Subtitle A, Part 21), and the assurance by the
Grantee pursuant thereto.
W C9M2titivoe Bidding. The Grantee shall not award or substantially
amend any contract in an amount greater than $10,000 pursuant to
the Project, except for professional service contracts, without
formal advertising, free, open, and unrestricted competitive bidding,
and award to the lowestresponsiveand responsible bidder, unless
UMTA specifically approves some other form of procurement or award
to another party upon being satisfied by the Grantee that such
action will adequately protect the Government's interests .in
encouraging competition, optimizing its cost; Provided, however,
the Grantee may issue change orders for competitively bid equip-
ment and construction contracts in an amount not exceeding
$100,000 at any one time which do not significantly alter the
scope of the Contract, without regard to the provisions of this
section.
(h) Ethics. The Grantee shall maintain a code or standards of conduct
which shall govern the performance of its officers, employees, or
agents in contracting with and expanding Federal grant funds.
Grantee's officers, employees, or agents shall neither solicit
nor accept gratiuties, favors, or anything of monetary value from
contractors or potential contractors. To the extent permissible
by State or local law, rules, or regulations such standards
18
shall provide for penalties, sanctions, or other disciplinary
actions to be applied for violations of such standards by
either the grantee officers, employees, or agents, or by contractors
or their agents.
Neither the Grantee nor any of its contractors or their subcontractors
shall enter into any contract, subcontract, or arrangement in
connection with the Project or any property included or planned
to be included in the Project, in>which any member, officer, or
employee of the Grantee or the locality during his tenure or
for one year thereafter has any interest, director indirect.
If any such present or former member, officer, or employee
involuntarily acquires or had acquired prior to the begining
of his tenure any such interest, and if such interest is in ediately
disclosed to the Grantee and such disclosure is entered upon the
minutes of the Grantee, the Grantee with the prior approval of
DOT, may waive the prohibition contained in this subsection;
Provided, that any such present member, officer or employee
gal —not participate in any action by the Grantee or the locality
relating to such contract, subcontract, or arrangement.
The Grantee shall insert in all Contracts entered into in
connection with the Project or in connection with any Property
included or planned to be included in any Project, and shall
require its contractors to insert in each of their subcontracts,
the following provision:
"No wd�er, officer, or employee of the Grantee or of the
locality during his tenure or for one year thereafter
shall have any interest, direct or indirect, in this
Contract or the proceeds thereof, but this provision
shall not be construed to extend to this Contract if
made with a corporation for its general benefit."
The provisions of this subsection shall not be applicable to any
agreement between the Grantee and its fiscal depositories, or
to any agreement for utility services the rates for which are
fixed or controlled by a Governmental agency.
M Interest of Members of or Delegates to Congress. No member of
or delegate to the Congress of the United States shall be admitted
to any share or part of this Grant Contract or to any benefit
arising thereform; but this provision shall not be construed to
extend to this Contract if made with a corporation for its general
benefit.
(J) Labor Provisions — Construction. The following provisions shall
be applicable to all construction contracts let by the Grantee
in carrying out the Project involving $2,000 or more.
19
(1) Mint= wages. (i) All mechanics and laborers employed or
working upon the site of the work, will be paidunconditionally
and not less often than once a week, and without subsequent
deduction or rebate on any account (except such payroll -
deductions as are permitted by regulations issued by.the
Secretary of Labor under the Copeland Act (29 CFR Part 3)), _
the full amounts due at time of payment canputed at wage
rates not less than those contained in the wage determination
decision of the Secretary of Labor applicable to the Project,
regardless of any contractual relationship which may be
alleged to exist between the contractor and such laborers
and mechanics; and the wage determination decision shall be
posted by the contractor at the site of the work in a
prominent place where ,it can be easily seen by the workers.
For the purpose of this clause, contributions made or costs
reasonably anticipated under section l(b)(2) of the Davis -
Bacon Act on behalf of laborers or mechanics are considered
wages paid to such laborers or mechanics, subject to the
provisions of 29 CFR 5.5 (a)(1)(iv) Also for the purpose
of this clause, regular contributions made or costs incurred'
for more than a weekly period under plans, funds, or programs,
but covering the particular weekly period, are deemed :to be i
constructively made or incurred during such weekly period.
(ii) The contracting officer shall require that any
class of laborers or mechanics, including apprentices and
trainees, that is not listed in the wage determination and
that is to be employed under the Contract, shall be classified
or reclassified conformably to the wage determination, and a
report of the action taken shall be sent by DOT to the
Secretary of Labor. In the event the interested parties cannot
agree on the proper classification or reclassification of a
particular class of laborers or mechanics, including
apprentices and trainees, to be used, the question accanPanied
by the rec mrendation of the contracting officer, shall be
referred to the Secretary of Labor for determination.
(iii) The contracting officer shall require; whenever
the minbm m wage rate prescribed in the contract for a
class of laborers or mechanics includes a fringe benefit
which is not expressed as an hourly wage -rate and the contractor
is obligated to pay a cash equivalent of such a fringe
benefit, an hourly cash equivalent thereof to be established.
in the event the interested parties cannot agree upon a
cash equivalent of the fringe benefit, the question, accompanied
by the recommendation of the contracting officer, shall be
referred to the Secretary of Labor for determination.
(iv) The contractor may consider as part of the wages
of any laborer or mechanic the amount of any costs reasonably
20
anticipated in providing benefits under a plan or program
described in a section l(b)(2)(B) of the Davis -Bacon Act,
or any bona fide fringe benefits not expressly listed in
Section l(b)(2) of the Davis -Bacon Act, or otherwise not
listed in the wage determination decisions of the Secretary
of Labor which are incorporated in this Contract, only when
the Secretary of Labor has found, upon the written request
of the contractor, that the applicable standards of the Davis -
Bacon Act have been meta Whenever practicable, the contractor
should request the Secretary of Labor to make such findings
before the making of the contract. In the case of unfunded
plans and programs, the Secretary of Labor may require the
contractor to set aside in a separate account assets for the
meeting of obligations under the plan or program.
(2) Withholding. DOr may withhold or cause to be withheld
from the contractor so much of the accrued payments or,
advances as may be considered necessary to pay laborers and
mechanics, including apprentices and trainees, employed by
the contractor or any subcontractor on the work the full
amount of wages required by the contract. In the event
of failure to pay any laborer or mechanic, including any
apprentice or trainee, employed or working on the site of
the work, all or part of the wages required by the contract,
DOT may, after written notice to the contractor, sponsor,
applicant, or owner, take such action as may be necessary
to cause the suspension of any further payment, advance,
or guarantee of funds until such violations have ceased.
(3) Payroll and basic records. (i) Payrolls and basic records
rela7ting thereto will be maintained during the course of the
work and preserved for a period of three years thereafter for
all laborers and mechanics working at the site of the work.
Such records will contain the name and address of each such
employee, his correct classification, rates of pay (ihcludi.ng
rates of contributions or costs anticipated of the types
described in section 1(b)(2) of the Davis Bacon Act), daily
and weekly number of hours worked, deductions made and actual
wages paid. Whenever the Secretary of Labor has found under 29
CFR 5.5 (a)(1)(iv) that the wages of any laborers or mechanics
include the amount of any costs reasonably anticipated in
providing benefits under a plan or program described in
section l(b)(2)(B) of the Davis -Bacon Act, the contractor shall
maintain records which show that the commitment to provide
such benefits is enforceable, that the plan or program is
financially responsible, and that the plan or program has
been communicated in writing to the laborers or mechanics
affected, and records which show the costs anticipated or
the actual cost inc tiurred in providing such benefits.
21
(ii) The contractor willsubmitweekly a copy of all
payrolls to the Grantee for transmission to DOT. The copy
shall be accompanied by a statement signed by the -employer
or his agent indicating that the payrolls are correct and -.
complete, that the wage rates contained therein are not less
than those determined by the Secretary of Labor and that
the classifications set forth for each laborer or riechanic
conform to the work he performed. A submission of the
"Weekly Statement of Camipliance't which is required under
this Contract and the Copeland regulations of the Secretary
of Labor (29 CFR, Part 3) and the filing with the intitial
payroll or any subsequent payroll of a.copy of any findings
by the Secretary of Labor under 29 CFR 5.5(a)(1)(iv) shall
satisfy this requirement. The prime contractor shall be
responsible for the submission of copies of payrolls of all
subcontractors. The contractor will make the records required
under the labor standards clauses of the contract available
for inspection by authorized representatives of DOT and the
Department of Labor, and will permit such representatives
to interview employees during working hours on the job.
Contractors employing apprentices or trainees under approved
programs shall include a notation on the first weekly certified
payrolls submitted to the contracting agencies that their
employment is pursuant to an approved program and shall
identify the program.
(4) Apprentices and Trainees .
(A) aEprenti.ces . Apprentices will be permitted to work
at less than the predetermined rate for the work they performed
when they are employed and individually registered in a bona
fide apprenticeship program registered with the U.S. Depart-
ment of Labor, Manpower Administration, Bureau of Apprentice-
ship and Training, or with a State Apprenticeship Agency
recognized by the Bureau, or if a person is employed in his
first 90 days of probationary employment as an apprentice in such an apprenticeship program, who is not individually
registered in the program, but who has been certified by the
Bureau of Apprenticeship and Training or a State Apprenticeship
Agency (where appropriate) to be eligible for probationary
employment as an apprentice. The allowable ratio of apprentices
to journeymen in any craft classification shall not be
greater than the ratio permitted to the contractor as to his
entire work force under the registered program. Any employee
listed on a payroll at an apprentice wage rate, who is not
a trainee as defined in subdivision (B) of this subparagraph
22
or is not registered or otherwise employed as stated above,
shall be paid the wage rate determined by the Secretary of
Labor for the classification of work he actually performed.
The contractor or subcontractor ',will be required to furnish
to the contracting officer or arepresentative of the Wage
Hour Division of the U.S. Department of.Labor written evidence
of the registration of his >lrogram and apprentices as well
as the appropriate ratios and wage rates texpressed in
percentages of the journeyman hourly rates) for the area
of construction prior to using any apprentices on the contract
work. The wage rate paid apprentices shall not be less than
the appropriate percentage of the journeyman's rate contained
in the applicable wage determination.
(B) Trainees. Except as provided in 29 CFR 5.15,trainees
will not Witted to work at less than the predetermined
rate for the work performed unless they are cloyed pursuant
to or individually registered in a program which has received
prior approval, evidenced by formal certification, by the U.S.
Department of labor, Manpower Administration, Bureau of
Apprenticeship and Training. The ratio of trainees to journey-
men shall not be greater than that permitted under the plan
approved by the Bureau of Apprenticeship and Training. Every
trainee moist be paid at not less than the rate specified in
the approved program for his level of progress. Any employee
Listed on the payroll at a trainee rate who is not registered
and participating in a training plan approved by the.Bureau
of Apprenticeship and Training shall be.paid not less than
the wage rate determined by the Secretary of Labor for the
classification of work he actually performed. The contractor
or subcontractor will be required to furnish the contracting
officer or a representative of the Wage -Hour Division of
the U.S. Department of Labor written evidence of the certifi-
cation of his program,the registration of the trainees, and
the ratios and wage rates prescribed in that program. in
the event the Bureau of Apprenticeship and Training withdraws
approval of a training program, the contractor will no
longer be permitted to utilize trainees at less than the
applicable predetermined rate for the work performed until
an acceptable program is approved.
(c) Equal employment opportunity. The utilization of
apprentices, trainees and journeymen under this part shall
be in conformity with the equal employment opportunity require-
ments of Executive Order 11246, as mended, and 29 CFR Part 30.
(5) Canpli.ance with Copeland Regulations (29 CFR Part 3).
The contractor shall comply with the Copeland Regulations
(29 CFR Part 3) of the Secretary of labor which are herein
incorporated by reference.
(6) Contract termination; debarment. A breach of clauses (1)
through (5) and (1) may be grounds for termination of the
contract, and for debarment as provided in 29 CFR 5.6.
23
(7) overtime requirements. No contractor or subcontractor
contracting for any part of the contract work which may requireor involve the employment of laborers orr mechanics'shall re-
quire or permit any laborer or mechanic in any workweek in
which he is employed on such work to work in excess of eight
hours in any calendar day or in excess of forty hours in
such workweek unless such laborer or mechanic receives
compensation at a rate not less than one and one-half times
his basic rate of pay for all hours worked in excess of -
eight hours in any calendar day or in excess of forty hours
in such workweek, as the case may be.
(8)-Violation; liability for unpaid wages; liquidated damages.
In the event of any violation of the clause set forth in sub-
paragraph (7), the contractor and any subcontractor responsible
therefor shall be liable to any affected employee for his
unpaid wages. In addition, such contractor and subcontractor
shall be liable to the United States (in the case of work
done under contract for the District of Columbia or a
territory, to such District or to such territory), for
liquidated damages. Such liquidated damages shall be camputed
with respect to each individual laborer or mechanic employed
in violation of the clause set forth in subparagraph (7), in
the sum of $10 for each calendar day on which such employee
as required or permitted to work in excess of eight hours
or in excess of the standard workweek of forty hours without
payment of the overtime wages required by the clause set
forth in subparagrah (7).
(9) Withholding for liquidated damages. DOT may withhold or
cause to be withheld, from any moneys payable on account of
work performed by the contractor or subcontractor, such sums
as may administratively be determimd to be necessary to
satisfy any liabilities of such contractor or subcontractor
for liquidated damages as provided in the clause set forth
in subparagraph (8).
(10) Final labor summary. The contractor and each subcontractor
shall furnish to the Grantee, upon the completion of the contract,
a summary of all employment, indicating, for the completed
Project, the total hours worked and the total amount earned.
(11) Final certificate. Upon completion of the contract,
the contractor shal submit to the Grantee with the voucher
for final payment for any work performed under the contract
a certificate concerning wages and classifications for laborers
and mechanics, including apprentices and trainees employed
24
on the Project, in the following form:
The undersigned, contractor on
(Contract No.)
hereby certifies that all laborers, mechanics, apprentices
and trainees employed by him or by a subcontractor per
forming work under the contract on the Project have been
paid wages at rates not less than those required by the
contract provisions, and that the work performed by each
such laborer, mechanic, apprentice or trainee conformed
to the classifications set forth in the contract or training
program provisions applicable to the wage rate paid.
Signature and title
(12) Notice to the Grantee of Labor Disputes. Whenever the
contractor has knowledge that any actual or potential labor
dispute is delaying or threatens to delay the timely per-
formance of this Contract, the contractor shall immediately
give notice thereof, including all 'relevant info=eticn with
respect thereto, to the Grantee.
(13) Disputes Clause (i) All disputes concerning the payment
of prevailing wage rates or classifications shall be pranptly
reported to the Grantee for its referral to DOT for decision
or, at the option of the Grantee, DOT referral to the Secretary
of Labor. The decision of DOT or the Secretary of Labor as
the case may be, shall lie final.
(ii) All questions relating to the application or
interpretation of the Copeland Act,'the Contract Work Hours
Standards Act, the Davis -Bacon Act, 'or Section 13 of the Act
shall be sent to UMM for referral to the Secretary of Labor
for ruling or interpretation, and such ruling or interpretation
shall be final.
(14) Convict Labor. In connection with the performance of.
work under this Cmtract the contractor agrees not to employ
any person undergoing sentence of imprisonment at hard labor.
This does not include convicts who are on parole or probation.
25
(15) Insertion in Subcontracts. The contractor shall insert
in all construction subcontracts the clauses set forth in
subsections (1) through (15). of this section so that all.
of the provisions of this section will be inserted in all
construction subcontracts of any tier, and such other clauses _
as the Goverment may by appropriate instructions require.
Section 110. Construction Contracts.
(a) Changes in Construction Contracts. Any change in a construction
contract shall be submitted to DOT for prior approval unless the
gross amount of the change is $100,000 or less, the Contract was
originally awarded on a competitive basis, and the change does not
change the scope of work or exceed the contract period. Construction
contracts shall include a provision specifying that the above
requirement will be met
(b) Contract Security. The Grantee shall follow the requirements of
the External Operating Manual with regard to bid guarantees and
bonding requirements (p. III C-16).
(c) Insurance During Construction. The Grantee shall follow the insurance
requirements normally required by their State and local governments-
(d) Signs. The Grantee shall cause to be erected at the site of
construction, and maintained during construction, signs satis-
factory to DOT identifying the Project and indicating that
the Government is participating in the development of the
Project.
(e) Liquidated Damages Provision. The Grantee shall include in all
contracts for construction, a clause satisfactory to DOT providing
for liquidated damages, if both (1) ?)Or may reasonably expect
to suffer damages (increased costs on the grant project involved)
from the late completion of the construction and (2) the extent
or amount of such damages would be difficult or impossible to
assess. The assessment for damages shall be at a specified rate
per day for each day of overrun in contract time deducted fran
payments otherwise due the contractor. This rate, which must be
satisfactory to DOT, must be specified in the Contract.
(f) Provisions of Construction Contracts. The terms and conditions of
each campetitive y bid construction contract are subject to prior
approval by DOT if the estimated cost will exceed $25,000. In
addition to the requirements of this Section 110, each construction
contract shall contain, among others, provisions required by
subsections (c), (f), (g), and (h) of Section 109 hereof.
921
(g) Actual Work by Contractor. The Grantee shall require that a
construction contractor perform, on the site and with his own
staff, work equivalent to at least 10 percent of the total
amount of construction work covered by his contract.
(h) Force Account. If costs of construction performed by employees
o 7 tthe Grantee are estimated to exceed $25,000, prior approval
of DOT must be obtained or else such costs may not be included
as eligible Project costs.
Section 111. Environmentaland Resource Protection Requirements
.
(a) Ccc2liance with Environmental Standards. The Grantee shall cotply
with the provisions of the Clean Air Act, as amended (42 U.S.C.
S1857 et seq.); the Federal Water Pollution Control Act, as
amended (33 U.S.C. S1251 et seq.); and implementing regulations
issued by the Environmental Protection Agency (EPA) , in the
facilities which are involved in the Project for which Federal
assistance is given in this Grant. The Grantee shall ensure that
the facilities under its ownership, lease or supervisen that shall
be utilized in the accomplishment of the Project are not listed
on the EPA's List of Violating Facilities and that the Grantee
shall notify UMTA of the receipt of any communication fron the
Director of the EPA Office of Federal Activities indicating that
a facility to be utilized in the Project is under consideration
for listing in EPA.
(b) Air Pollution. No facilities or equipment shall be acquired
constructed, or improved as a part of the Project unless the
Grantee obtains satisfactory assurances that they are (or will be)
designed and equipped to limit air pollution as provided in the
External Operating Manual and in accordance with all other
applicable standards.
(c) Use of Public Lands. No publicly owned land from a park, recreation
area, or wildlife and waterfowl refuge of national, State, or
local significance as determined byIthe Federal, State, or local
officials having jurisdiction thereof, or any land from an historic
site of national, State, or local significance as so determined
by such officials may be used for the Project without the prior
concurrence of DOT.
(d) Historic Preservation. The Grantee shall assist tHM in its
compliance with Section 106 of the National Historic Preservation
Act of 1966, as amended (16 U.S.C. 470), Executive Order
No. 11593, and the Archeological and Historic Preservation Act
of 1966 (16 U.S.C. 469a-1 et seq.) by (a) consulting with the
State Historic Preservation Officer on the conduct of investigations,
as necessary, to identify properties listed in or eligible for
27
inclusion in the National Register of Historic Places that are
subject to adverse effects (see 36 CFR Part.800.8),by the activity,
and notifying EMTA of the existence of any such properties, and i
by (b) complying with all requirements established by [4CA to
avoid or mitigate adverse effects upon such properties.
Section 112. Patent Rights
(a) Whenever any invention, improvement, or discovery (whether or not
patentable) is conceived or for the first time actually reduced to
practice, by the Grantee or its employees, in the course of, in
connection with, or under the terms of this Contract: the Grantee
shall immediately give the Secretary of DOT, through UM.. or
his authorized representative written notice thereof; and the
Secretary shall have the sole and elusive power to determine
whether or not and where a patent application shall be filed, and to
determine the disposition of all rights in such invention, improve-
ment, or discovery, including title to and rights under any patent
application or patent that may issue thereon. The determination
of the Secretary on all these matters shall be accepted as final,
and the Grantee agrees that it will, and warrants that.all of its
employees who may be the inventors will, execute all documents
and do all things necessary or proper to the effectuation
of such determination.
(b) Except as otherwise authorized in writing by the Secretary or
his authorized representative, the Grantee shall obtain patent
agreements to effectuate the provisions of this clause from all
persons who perform any part of the work under this Contract,
except such clerical and manual labor personnel as will have no
access to technical data.
(c) Except as otherwise authorized in writing by the Secretary or
his authorized representative, the Grantee will insert in each
third -party contract having design, test, experimental, develop-
mental, or research work as one of its purposes, provisions
making this clause applicable to the third -party contractor and
its employees.
(d) If the Government obtains patent rights pursuant to this clause
of this Contract, the Grantee and the third -party contractor
shall be offered license rights thereto on terms at least as i
favorable as those offered to any other party. However, in the
event no effective steps have been taken by the Grantee or the #
third -party contractor or any other party within 3 years after
issuance of a patent under which the Government acquires rights
pursuant to this clause to bring the claimed invention to the
point of practical application, the Government's obligation to ;
28
offer a license pursuant to this clause shall terminate, and any
license already granted to the Grantee or the third -party contractor
pursuant to this clause shall be revoked unless the Grantee or,
the third -party contractor can show cause as to why such license
shall not be revoked.
(e) In the event no inventions, improvements, or discoveries (whether
or not patentable) are conceived, or for the first time actually
reduced to practice by the Grantee, its employees, its third -
party contractors, or their employees, in the course of, in
connection with, or under the terms of this Contract, the Grantee
shall so certify to the Secretary or his authorized representative,
no later than the date on which the final report of work done, is
due.
(f) If the Grantee or the third -party contractor is permitted to file
patent applications pursuant to. this Contract, the following
statement shall be included within the first paragraph of the
specification of any such patent application or patent:
"The invention described herein was made in the course
of, or under, a grant from the Department of Trans-
portation."
(g) In the event the Grantee or the third -party contractor is permitted
to acquire principal rights pursuant to this clause and fails to
take effective steps within 3 years after issuance of a patent
on any patent applications permitted to be filed pursuant to this
clause to bring the claimed invention to the point of practical
application, the Secretary or his authorized representative may
revoke such rights or require the assignment of such rights
to the Government.
(h) The Secretary or his authorized representative shall, before the
expiration of three (3) years after final payment under this
grant, have the right to examine any books, records, documents,
and other supporting data of the Grantee which the Secretary or
his authorized representative shall reasonably dean directly
pertinent to the discovery or identification of inventions
falling within the criteria set out in paragraph (a), or to
compliance by the Grantee with the requirements of this clause.
The Secretary or his authorized representative shall, during
the period specified above, have the further right to require the
Grantee to examine any books, records, documents, and other
supporting data of the third -party contractor which the Grantee
shall reasonably deem directly pertinent to the discovery or
29
identification of inventions falling within the criteria set
out in paragraph (a) or to compliance by the third -party
contractor with the requiremnts of the patent rights clause
of the third -party contract.
Section 113. Rights in Data.
(a) The tenn "subject data" as used herein means recorded information,
whether or not copyrighted, that id delivered or specified to
be delivered under this Contract. The teen includes graphic
or pictorial delineations in media such as drawings or photographs;
text in specifications or related performance or design -type
its; machine forms such as punched cards, magnetic tape,
or computer memory printouts; and information retained in computer
memory. Examples include, but are not limited to,.engi.neering
drawings and associated lists, specifications, standards, process
sheets, manuals, technical reports, catalog item.identifications,
and related information. The tenn does not include financial reports,
cost analyses, and similar information incidental to contract
administration.
(b) All "subject data" first produced in the performance of this
Contract shall be the sole property of the Government. The
Grantee agrees not to assert any rights at common law or equity
and not to establish any claim to statutory copyright in such data.
Except for its own internal use, the Grantee shall not publish or
reproduce such data in whole or in part, or in any manner or form,
nor authorize others to do so, without the written consent of the
Government until such time as the Government may have released
such data to the public.
(c) The Grantee agrees to grant and does hereby grant to the Government
and to its officers, agents, and employees acting within the
scope of their official duties, a royalty -free, nonexclusive, and
irrevocable license througtout the world (1) to publish, translate,
reproduce, deliver, perform, use, and dispose of, in any manner,
any and all data not first produced or composed in the performance
of this Contract but which is incorporated in the work furnished
under this Contract and (2) to authorize others so to do.
(d) The Grantee shall indemnify and save and hold harmless the Government,
its officers, agents, and employees acting within the scope of
their official duties against any liability, including costs and
expenses, resulting from any willful or intentional violation by
the Grantee of proprietary rights, copyrights, or rights of privacy,
arising out of the publication, translation, reproduction, delivery,
performance, use, or disposition of any data furnished under this
Contract.
30
(e) Nothing contained in this clause shall imply a license to the
Government under any patent or be construed as affecting the
scope of any license or other right otherwise granted to the
Government under any patent.
(f) In the event that the Project, which is the subject of this Contract,
is not completed, for any reason whatsoever; all data generated
under that Project shall became subject data as defined in the
Rights in Data clause in this'Contract and shall be delivered
as the Government may direct. This clause shall be included in
all third -party contracts under the Project.
(g) Paragraphs (c) and (d) above are not applicable to material furnished
to the Grantee by the Government and incorporated in the work fur-
nished under the contract; provided that such incorporated material
is identified by the Grantee at the time of delivery of such work.
Section 114. Cargo Preference - Use of United States -Flag Vessels.
(a) Pursuant to Pub. L.'664 (46 U.S.C. 1241(b)) at Least 50 percent
of any equipment, materials or commodities procured, contracted
'for or otherwise obtained with funds granted, guaranteed, loaned,
or advanced by the U.S. Government under this agreement, and
which may be transported by ocean vessel, shall be transported
on privately -owned United States -flag commercial vessels, if
available.
(b) Within 20 days following the date of loading for shipments
originating within the United States or within 30 working days
following the date of loading for shipments originating outside
the United States, a legible copy of a rated, "on -board" commerical
erical
ocean bill -of -lading in English for each shipment of cargo described
in paragraph (a) above shall be furnished to the Division of
National Cargo, Office of Market Development, Maritime Adminis-
tration, Washington, D.C. 20230 marked with appropriate identification
of the Project. The Grantee shall also obtain a copy of any such
bill -of -lading (through the prime contractor in the case of
subcontractor bills -of -lading) and retain records of the bill -of -
lading and any supporting documents for a period of three years
following closeout of the Project.
(c) The Grantee agrees to insert the following clauses in all contracts
let by the Grantee in carrying out the Project:
Cargo Preference - Use of United States -Flag Vessels.
The contractor agrees --
(1) To utilize privately owned United States -flag damnercial
vessels to ship at least 50 percent of the gross tonnage (ccsputed
separately for dry bulk carriers, dry cargo liners, and tankers)
involved, whenever shipping any equipnLelt, materials, or commodities
31
pursuant to this Contract, to the extent such vessels are available
at fair and reasonable rates for United States -flag ca wrcial
vessels.
(2)`To furnish within 20 days following the date of loading for shipments originating within the United States, or within 30
working days following the date of loading for shipments originating
outside the United States, a legible copy of a rated, "on -board"
canenercial ocean bill -of -lading in English for each shignent of
cargo described in paragraph (1) above to the Grantee (through,
the prime contractor in the case of subcontractor bills -of -lading)
and to the Division of National Cargo,. Office of Market Develop-
ment, Maritime Administration, Washington, D.C. 20230, marked
with appropriate identification of the Project.
. (3) To insert the substance of the provisions of this clause
in all subcontracts issued pursuant to this Contract.
Section 115. Charter School Bus Operations.
(a) Charter Bus. The Grantee, or any operator of mass transportation
acting on its behalf, shall not enagage in charter bus operations
outside the urban area within which it provides regularly scheduled
mass transportation service, except as provided under Section 3(f)
of the Urban Mass Transportation Act of 1964, as amended, and
published U11A regulations on charter bus operations.
(b) School Bus The Grantee, or any operator of mass transportation
acting on its behalf, shall not engage in school bus operations,
exclusively for the transportation of students or school personnel,
in competition with private school bus operators, except as provided
under Section 3(g) of the Urban Mass Transportation Act of 1964,
as amended, and published UMTA regulations on school bus operations.
Section 116. Compliance with Elderly and Handicapped Regulations. The
Grantee shall insure that all fixedfacility construction or alteration
and all new equipment included in the Project comply with applicable
provisions of 49 CFR Part 609 -- Transportation for Elderly and Handi-
capped Persons
Section 117. Flood Hazards. The Grantee shall comply with the flood
insurance purchase requirements with respect to construction or acquisition
purposes, of Section 102(a) of the Flood Disaster Protection Act of 1973,
Public Law 93-234,87 Stat. 975.
32
Section 118. Miscellaneous.
(a) Bonus or Conmiissicn. The Grantee warrants. that it has not paid,
19 also agrees not to pay, any bonus or commission for the purpose
of obtaining an approval of its application for the Grant hereunder.
(b) State or Territorial Law. Anything in the Grant Contract to the
contrary notwithstanding, nothing in the Grant Contract shall
require the Grantee to observe or enforce ccnpliance with any
provision thereof, perform any other act or do any other thing
in contravention of any applicable State or territorial law;
Provided, That if any of the provisions of the Grant Contract
violate any applicable State or territorial law, or if commliance
with the provisions of the Grant Contract would require the
Grantee to violate any applicable State or territorial law, the
Grantee will at once notify DOT in writing in order that appropriate
changes and modifications may be made by DOT and the Grantee to
the end that the Grantee may proceed as soon as possible with
the Project.
(c) Records. The Grantee,.and any mass transportation operator for
U i iich t applies will conform to the reporting system and the
uniforn system of accounts and records to the extent required by
section 15 of the Urban :Mass Transportation Act of 19r,4, as amended,
effective for each local fiscal year ending on or after July 1,
1978, and published LZM regulations.
(d) How Contract Affected by Provisions Held Invalid. If any provision
of this Contract is held invalid, the remainder of this Contract
shall not be affected thereby if such remainder would then continue
to conforn to the terms and requirements of applicable law.
33
r
0