Loading...
HomeMy WebLinkAboutResolution - 369 - Contract- Anthony Mechanical- GWO 10982, Phase I Renovations At SE WR Plant - 12_12_1979RESOLUTION #309 - )12/12/79 Bri #561-8 RESOLUTION WHEREAS, the City Council of the City of Lubbock has considered bids for construction work to be done on phase No. 1 renovation of Plant No. 1 Southeast Water Reclamation Plant for the City of Lubbock, Texas, and after due consider- ation of said bids the City Council has determined that the lowest and best bidder is Anthony Mechanical, Inc., of Lubbock, Texas, and, WHEREAS, the City Council of the City of Lubbock finds it would be in the public interest to enter into a Contract for such improvements; NOW THEREFORE, BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF LUBBOCK: THAT the Mayor of the City of Lubbock is hereby authorized and directed to execute for and on behalf of the said City a Contract to be entered into by and between said City and Anthony Mechanical, Inc., for G.W.O. 10982 for construction improvements as regards phase No. 1 renovation of Plant No. 1 Southeast Water Reclamation Plant. The amount of such Contract is $434,662.00. Passed by the City Council this 12th day of December ,1979. A AlkAA:Ain ne, 4INZI) ATTEST: Evelyn--Ga fga, City Secr t -Treasurer ^APPROVEI? AS TO FORM: . n v V 11 - V + J./titrth Fullingim, Asst. C Oty Attorney APVOVED AS TO CONTENT: Sam Wahl, Director o Utilites City Engineer /2'1_�5(1p9 'vj rN 762-6411 P. O. Box 2000 LUBBOCK, TEXAS 79457 Certificate of Completion Honorable Mayor and City Council City of Lubbock, Texas Gentlemen: On May 18, 1981 the contract, Phase No. 1 Renovation, Plant No. 1 Southeast Water. -Reclamation Plant, G.W.O. 10982, constructed by Anthony Mechanical Inc., -_under contract dated December 12, 1979, was inspected and found said improvements to have been completed in accordance with the plans and specifications. Therefore, I recommend that you accept said improvements and authorize final payment to the contractor. Very truly yours, Wilfo d D. Watson Chief Water Utilities Engineer CITY S1CRfTARY MONTHLY ESTIMATE CITY. OF LUBBOCK r Project:Phase No. 1-Renovation of Plant No. 1 Contractor: Southeast Water Reclamation Plant Address: Anthony Mechanical Inc. P. 0. Box 2706, Lubbock, Texas 79408 Project No36-0001-14800-010982 Estimate No: 16 & Final Contract S - 411.07.1.:GO Page 1 of 2 r Estimate Period From May 20 , 1981 to June 10 , 1981 On First estimate and final estimate use actual work dates ITEM UNIT OF MEASURE PROJECT EST, QUANTITIES WORK DONE ON CONTRACT CONTRACT PRICE AMOUNT 24 inch -approved VCT sewer pipe, furnished and installed including fittings, complete in place, 0-8' cut, per linear oot: L.F. 383 383 93.00 35 619.00 Concrete box extension on exis7 ting,junction box, furnished and installed including sli- j ding gate and hand crank, com- fete in place, lump sum, L.S. 100% p 6890.00 3. Concrete box as shown on plans for rectiving primary furnished and installed., inclui ding'sliding izate and had I I crank complete in place.- -lump sum: L.S. + 100% I e 10 800.00 4. Plastic filter Media furnish- ed and installed complete in lace, per cubic yard, C.Y. 3160 2900 76.00 220,400.00 5. Filter Distributor 4 arm Me1 I including center as m fur.. nished and installed complete in place, per each Each ! 2 9 25 30Q.00 { i { I I I I I MONTHLY ESTIMATE - CITY OF LUBBOCK Project: Phase No. 1-Renovation of Plant No. 1 Project No. 6-nnni —14800-01098 Contractor: Anthony Mechanical Inc.. Estimate No. 16 & Final Address: P.O. Box 2706 Contract 411,071.00 Lubbock, Texas 79408 Page 2 of 2 Estimate Period From May 20 , 19 81 to June 10 , 19 81 On First estimate and final estimate use actual work dates ITEM UNIT OF MEASURE PROJECT EST. QUANTITIES WORK DONE ON CONTRACT CONTRACT PRICE AMOUNT 6 A and imstalled. including motor starter, suction piping. DumD base plate, discharge pipinyt, and necessary fittings for a complete installation,. lump sum L.S. 100% 1002 11,000.00 7. High Rate vitrified clay fil- ter block furnished and in- d complete in place, per square foot S . Ft.1 10,598 10 598 5.00 52 990.00 I t Chanlze Order No. 1 1 599.00 1,599.00 Chan a Order No. 3 !3-00 I I I i I j I I I I t For En Total Amount of Work Done ....... $ 391, 311. 00 Less 10% Retained Difference ...................... $ ' Less Special Deduction .. , . , ; $' . Less Liquidated Damage Less Previous Payments....:..'.... 5 377,179.90 Amount Due this Estimate......... $ 14,131:10 0 To: Anthony Mechanical Inc. P. 0. Box 2706 .Lubbock, Texas 79408 Original Amount of the contract Net amount this change order Amended amount of contract Additional time of completion _ Change Order No. 1 Phase No. 1 Renovation of Plant No. 1 E. Water Reclamation Plant GWO 10982 $408,059.00 $ 1,599.00 $409,658.00 None WHEREAS, it is desirable to make changes in the plans and specif ications for this project; THIS AGREEMENT WITNESSETH: In consideration of the mutual advantages gained, the Owner and the Contractor agree. to the change shown herein and in the attached exhibits and data and the Owner and the Contractor agree that the original contract between them shall be modified and amended to the extent herein indicated. IN WITNESS WHEREOF, the Owner and the Contractor have hereto set their hands this the 8th day of May, 1980. Anthony Mechanical, Inc. By rontr�actor + -f9_eS•CQ� CITY OF LUBBOCK OWNER By Mayor ATTEST: City Secre ry REC ED FO APPROV r Chfef gineer, Water Utilities Engineering li _GWO 10,982 - Change Order #1 and <Approp. Ord. 8047, 5/8/80 (Change Order #1 is on file w/Reso 369) Change Order,# 2 - Reso 603, 9/11/80; Change Order 3 - Reso 618' 9/25/80, Chgnge_Order$4 Reso 7i91a�/a/�/ To: Anthony'Mechanical Inc. P. 0. Box 2706 .Lubbock, Texas 79408 Original Amount of the contract Net amount this change order Amended amount of contract Additional time of completion Change Older No. 1 Phase No. 1 Renovation of Plant No. /SE. Water Reclamation Plant .V GWO 10982 $408,059.00 $ 1,599.00 $409,658.00 None WHEREAS, it is desirable to make changes in the plans and specifications for this project; I THIS AGREEMENT WITNESSETH: In consideration of the mutual advantages gained, the Owner and the Contractor agree• to the change shown herein and in the attached exhibits and data and the Owner and the Contractor agree that the original contract between themshall be modified and amended to the extent herein indicated. i i IN WITNESS WHEREOF, the Owner and'the Contractor have hereto set their hands this the 8th day of May, 1980. Anthony Mechanical, Inc. By Contractor . Rre5 !CITY OF LUBBOCK ,OWNER i7 By Mayor jATTEST: City Secre ry RECO NDED FO APPROV Chief gineer, Water Utilities Engineering 1 FORM L-2 AN APPROPRIATION ORDINANCE ORDINANCE NO. 8047 WHEREAS, the City Council of the City of Lubbock finds it is necessary to appropriate certain specific funds for an approved project: NOW THEREFORE, BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF LUBBOCK: There is hereby appropriated out of the following described fund, to -wit: Sanitary Sewer Capital Project Fund The sum $ 1,599.00 For the following purpose: Install four light fixture poles $1,058.00 Concrete blocks for filter floor channel 541.00 $1,599.00 36-0001-14800-01982 THAT the fact that public necessity and convenience requires that this Ordinance be passed as an emergency measure for reasons set forth in the preamble hereof, the rule requiring that no Ordinance shall be finally passed on the day of its introduction be suspended, and this Ordinance is declared to be an emergency measure to take effect from and after its passage and publication as set forth hereinabove. AND IT IS SO ORDERED Passed by the City Council this 8th day of May 1980. Passed by the City Council this 22nd day of 1 0 MAYOR ATTEST: VERIFIED APPROVED BY JWF:bs RESOLUTION #603 - 9/11/80 VlFQnT_irrTnM BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF LUBBOCK: THAT the Mayor of the City of Lubbock is hereby authorized and directed to execute a change order on behalf of said City with the Contractor, being Anthony Mechanical, Inc., on a contract with respect to Phase No. 1 Renovation of Plant No. 1 S.E. Water Reclamation Plant C.W.O. 10982, being known as Change Order No. 2 attached herewith and made a part hereof as if fully copied herein in detail., Passed by the City -Council this ATTEST: llth day of September 1980 BILL McALISTER, MAYOR �velyn Ga Kga, City S cr t -Treasurer APPR VED AS TO CONTENT: 0; JlChief LVjineer, Water Utilities j; Enginee ing APPROVED AS TO FORM: J. rth Fullingim, Asst. Oity Attorney anthony mechanical, inc. mechanical contractors p. o. box 2706/525 e. 40th lubbock, texas 79408 phone (806) 747-4151 August 20, 1980 City of Lubbock P.O. Box 2000 Lubbock, Texas 79457 Attn: Mr. Richard Barton Re: Southeast Water Reclamation Plant G.W.O. 10,982 Gentlemen: _ Due to conditions completely beyond our control, we must request a time extension for the subject contract. We have not been able to get Mass Transfer (henceforth to be referred to as MT) to deliver the filter media for bid item A. We have continuously pursued this order from day one and to date have not received one piece of material on jobsite. Our best efforts have been rewarded with no response from MT. A chronology of our dealings with MT follows: (1) -12/05/79 - we receive a phone quote from Norm Berthusen of Newport Industries representing MT with delivery quoted as 26 - 28 weeks (2) 12/08/79 - Newport Industries confirms verbal with written quote (3) 12/21/79 - we are awarded subject contract by you with time of completion 270 days, making 9/16/80 the date of completion (4) 01/08/80 - we award our P.O. #22397 and note on the face thereof the time importance - we set forth that delivery shall begin 12 weeks after MT receipt of approved submittal and finish by the 24tn week ` (5) 01/15/80 - MT acceptance letter of our P.O. #22397 takes exception to our delivery dates and restates delivery to be 26-28 weeks after approval (6) 01/28/80 (approximate date) - we receive a sample for approval - we request additional data for evaluation (7) 02/12/80 - letter of transmittal for additional data (8) 02/14/80 - approval obtained from city engineer (9) 02/14/80 - our release to Newport Industries TO: Anthony Mechanical Inc. P.O. Box 2706 ' Lubbock, Texas 79408 Original Amount of the Contract Change Order #1 Amended Amount of Contract Original Date of Completion Additional Time of Completion Amended Date of Completion iaSULUl'i0N ;/603 - 9/11/80 Change Order No. 2 Phase No. 1 Renovation of Plant No. S.E. Water Reclamation Plant GWO 10982 $408,059.00 $ 1,599.00 $409,658.00 September 16, 1980 19 weeks January 27, 1981 WHEREAS, it is desirable to make changes in the plans and specifications for this project; THIS AGREEMENT WITNESSETH: In consideration of the mutual advantages gained, the Owner and the Contractor agree to the change shown herein and in the attached exhibits and data, and the Owner and the Contractor agree that the original contract between them shall be modified and amended to the extent herein indicated. IN WITNESS WHEREOF, the Owner and the Contractor have hereto set their hands this the llth day of September, 1980. Anthony Mechanical, Inc. CITY eOFLOCK OWNER .1 By Mayor ATTEST: Cit Secretary RECO ND FOR APPROV r Chi ngineer, Water Utilities Engi- neering -AI3TH64 MECHANICAL, INC. City of Lubbock August 20, 1980 Page 2 (10) early April our expiditer begins checking on order status - contacts are made by phone to Norm Berthusen (11) 04/23/80 - phone contact made to Roddy Landon in Houston office of MT (note that at this point we are going direct to MT for answers) - first shipment promised 5/16/80 (12) 05/06/80 - phone contact to Landon - he advises they are having mold problems and 1st shipment will be 5/30/80 (13) 05/09/80 - phone contact with Landon and Berthusen - continuing problems with mold (14) 05/14/80 - phone contact - no new info (15) 05/16/80 - phone contact with Berthusen - still having problems with mold - now 1st shipment is indefinite (16) 05/21/80 - phone contact with Landon - mold will not work (17) 05/30/80 - phone contact with Landon - trying to get another mold from England (18) 06/05/80 - phone contact with Landon - another mold coming from overseas and schedule will be met-iff acknowledged the critical time of completion (19) 06/11/80 - phone contact with Landon - no further info (20) 06/13/80 - phone contact with Berthusen - no further info (21) 06/18/80 - no further info ' (22) 06/23/80 - phone contact with Landon - mold coming off another job in England - will arrive 1st week in July - Texas Plastics in 'Midland will be making the product (23) 06/25/80 - phone contact with Jack Hawkey of Texas Plastics - he says that shipping of samples to England for approval will cause a two week delay (24) 07/02/80 - phone contact with Landon - mold is being secured from another job - he will check on waiving approval in England (25) 07/07/80 - phone contact with Landon - no further info (26) 07/09/80 - phone contact with Landon and Hawkey (27) 07/10/80 - phone contact with Bill Watkins - VP` in charge of production in England (transatlantic call) - he advises that an additional mold will be available in order to meet the schedule (28) 07/14/80, 07/15/80, 07/16/80, 07/17/80 - phone conversations with Landon and Geri Todd of MT - they give us shipping schedule for mold, when it will clear customs, etc - mold supposedly will arrive in Midland 07/21/80 (29) 07/18/80 - phone contact with Jack Hawkey of Texas Plastics and he gives us production info when he gets the mold (30) 07/21/80 - phone contact with Geri Todd - mold delayed and will not arrive till 07/22/80 - also an additional mold being used for a job in France will be diverted here in mid -August (31) 07/23/80 - phone contact with Geri Todd - mold is in customs (32) 07/25/80 - phone contact with Hawkey - he received mold at 10:00 AM - will start production Monday (33) 07/30/80 - phone contact with Hawkey - will run samples for approval ANtHO,,'h MECHA;UCAL, INC. City of Lubbock August 20, 1980 Page 3 (34) 08/01/80 - phone. contact with Geri Todd - samples received and approved - no further info on mold from France (35) 08/04/80 - phone contact with Hawkey - ordered material for production - production will begin Monday 8/11/80 (36) 08/06/80 - phone contact with Hawkey - production is beginning - should ship first load 8/12/80 (37) 08/11/80 - phone contact with Hawkey - production problems - trying mold on another machine (�8) 08/13/80 - phone contact with Hoover (1.h-charge of production at Texas Plastics) - all material on hand is contaminated - new material being ordered (39) 08/15/80 - phone contact with Hoover - received new material and back in production - they will advise when 1st shipment is ready (40) 08/18/80 - phone contact with Hoover - producing product with no problems - samples have been run with a second mold (41) 08/20/80 - phone contact with Hoover - 1st shipment is to arrive jobsite on 08/21/80 - current production is at 12,000 pieces daily and will require 22 weeks to complete - samples from 2nd mold were not approved - 2nd mold will not be available for 3 to 4 weeks. The above record does not mention many phone calls.made by us which were not answered. We feel the record speaks in our favor in our efforts to secure shipment of the filter media. We have spent many hours and many dollars trying to get MT to keep their promises. The finish date of this job is entirely at their whim, and apparently their whim is to direct their productive efforts in other parts of the world. The current productive rate by Texas Plastics will result in the final delivery about 22 weeks from this date, We therefore request a 19 week time extension tbthe subject contract. We apologize for this poor performance. Perhaps this chronology will aid you in your evaluation of choice of media for your future requirements. Thank you for your consideration. Yours truly, ANTHONY MECHANICAL, INC. OA"tk� �. Arthur E. Cronk President AEC/vra cc: Mass Transfer cc: Newport Industries The Contractor further agrees that he will commence work within ten (10) days after the date written notice to do so shall have been given to the Contractor, and will progress therewith so that the work shall be substantially completed in accordance with the terms of this Agreement. By the term "substantially completed" is meant that the structure has been made suitable for use or occupancy and is in condition to serve its intended purpose, but still may require minor miscellaneous work and adjustment. 46. EXTENSION OF TIME The Contractor agrees that he has submitted his proposal in full recognition of the time required for the completion of this project and has . considered the liquidated damage provisions of paragraph 47 herein and that he shall not be entitled to nor will he request an extension of time on this 5:•'''' contract except when his work has been delayed.by an act or neglect of the Owner or En ineer or 'of an employee of either or other contractors employed b the -, •, . g YYY Owner, or by changes ordered in the work,. or by strike, lockouts, fire and unusual delays by common carrier, and unavoidable cause or causes beyond the Contractor's control. The Contractor may apply for extension of time as justified Wow and provided herein in writing to the city engineer within 10 days after the act has occurred which would tend to justify an extension of time and the engineer• shall submit such written request to the City Council for their, consideration. Should the contractor disagree with the action of the City Council_ on granting an extension of time, the disagreement shall be settled as provided by paragraph 44 herein. 47. LIQUIDATED DAMAGES FOR DELAY The Contractor agrees that the completion date set forth in the proposal is an essential element of the contract, and that if the Contractor fails to substantially complete the work by said completion date or by an extension date if allowed, the owner may permanently withhold seventy-five dollars (75.00) for each working day thereafter. A working day will be considered any day, except legal holidays and Sundays, that, in the judgment of the engineer, the contractor -is able or would be able to efficiently employ more than one-half O of his equipment for.more than four (4) hours. (OR) 48. RECIPROCAL RE[dARD FOR DELAYED OR EARLY COMPLETION Time for completion is of the essence of this contract, by -reason whereof, it reciprocally is agreed: (a) . For each day of delay in completion beyond the number of working days herein agreed upon for completion of the work (after allowance for "Extension of Time", as provided for in paragraph 46 hereof) -the OWNER shall withhold from the CONTRACTOR'S compensation then unpaid the sum of Dollars ($ ), which shall be applied as liquidated damages; (b) in case the work be completed in fewer days than the number agreed on for completion; II - 15 043 1970 The Contractor further agrees that he will commence work within ten (10) days after the date written notice to do so shall have been given to the Contractor, and will progress therewith so that the work shall be substantially completed in accordance with the terms of this Agreement. By the term "substantially completed" is meant that the structure has been made suitable for use or occupancy and is in condition to serve its intended purpose, but still may require minor miscellaneous work and adjustment. 46. EXTENSION OF TIME The Contractor agrees that he has submitted his proposal in full recognition of the time required for the completion of this project and has . considered the liquidated damage provisions of paragraph 47 herein and that he shall not be entitled to nor will he request an extension of time on this contract except when his work has been delayed by an act or neglect of the Owner {.' or Engineer or of any employee of either or by other contractors employed by the Owner, or by changes ordered in the work, or by strike, lockouts, fire and unusual delays by common carrier, and unavoidable cause or causes beyond the - _ i$i'�atuaiarr�c�sn.. ya1..��sr`u�s s���a ■ _.Qontract�orrt scontrol. The Contractor may apply for extension of time as justified and provided herein in writing to the city engineer within 10 days after the act has occurred which would tend to justify an extension of time and the engineer. shall submit such written request to the City Council for their consideration. Should the contractor disagree with the action of the City Council on granting an extension of time, the disagreement shall be settled as provided by paragraph 44 herein. 47. LIQUIDATED DAMAGES FOR DELAY. The Contractor agrees that the completion date set forth in the proposal is an essential element of the contract, and that if the Contractor fails to substantially complete the work by said completion date or by an extension date if allowed, the owner may permanently withhold seventy-five dollars (75.00) for each working day thereafter. A working day will be considered any day, except legal holidays and Sundays, that, in the judgment of the engineer, the contractor -is able or would be able to efficiently employ more than one-half (') of his equipment for.more than four (4) hours. 48. RECIPROCAL REIIARD FOR DELAYED OR EARLY MMETION Time for completion is of the essence of this contract, by -reason whereof, it reciprocally is agreed: (a) For each day of delay in completion beyond the number of working days herein agreed upon for completion of the work (after allowance for "Extension of Time", as provided for in paragraph 46 hereof) the OW ER shall withhold from the CONTRACTOR'S compensation then unpaid the sum of Dollars ($ ), which shall be applied as liquidated damages; (b) in case the work be completed in fewer days than the number agreed on for completion; II - 15 043 1970 r�l RE TION #618 - 9/25/1 JWF : bs ZCiG� �D, yid RESOLUTION BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF LUBBOCK: THAT the Mayor of the City of Lubbock is authorized and directed to execute for and on behalf of the City of Lubbock Change Order No. 3 to Phase No. 1 Renovation of Plant No. 1, S.E. Water Reclamation Plant, said change order to be entered into with Anthony Mechanical, Inc., the contractor on said phase of this project, a copy of which change order is attached hereto and made a part hereof. Passed by the City.Council this 25th day of September , 1980. 4IMcALIS�*ER*.,MAYOR ATTEST: 2, �2z,, Ev lyn Gaf ga, City S r -Treasurer APPROVED AS TO CONTENT: Guy Wilspii,Senior Civil Engineer, Water Upilities APPROVED AS TO FORM: J. Vth Fullingim, Asst. City At ney . "V- . I bULUTiON it -"618 - 9/25/80 �,0 TO: Anthony Mechanical, Inc. P.O. Box 2706 Lubbock, Texas 79408 Original Amount of Contract Change Order #1 Amended Amount of Contract Original Date of Completion Change Order #2 (Additional Time of Completion) Amended Date of Completion Change Order #3 Amended Amount of Contract Change Order No. 3 Phase No. 1 Renovation of Plant No. S.E. Water Reclamation Plant G. W. 0. 10982 $ 408,059.00 1,599.00 409,658.00 September-16, 1980 19 weeks January 27, 1981 $ 1,413.00 $ 411,071.00 WHEREAS, it is desirable to make changes in the plans and specifications for this project: THIS AGREEMENT WITNESSETH: In consideration of the mutual advantages gained, the Owner and the Contractor agree to the change shown herein and in the attached exhibits and data, and the Owner and the Contractor agree that the original contract between them shall be modified and amended to the extent herein indicated. IN WITNESS WHEREOF, the Owner and the Contractor have hereto set their hands this the 25th day of September, 1980. Anthon Mechanical, Inc. CITY OF L74K 8, 6t"-e� OWNER By y aorr ATTEST: RECOMMENDED FAR cnierengineer, Engin ring 'PROVAL : iter Uti es Attachment to Change Order No. 3 Anthony Mechanical, Inc.. G.W.O. 10982 Exalanation of Change Furnishing paint and painting.two trickling filter distributors. Each distributor has four distribution arms. The cost of painting is based on one coat of Tnemec coal tar epoxy top coat #A6H413 sprayed with a dry coat thick- ness of approximately 16 mils. Breakdown of Change Furnishing paint and labor $ 1284.55 10% mark-up 128.45 Total amount of Change Order $ 1413.00 JWF:dh RESOLUTION #718 - 2/12/81 Amends Reso. #369, . 12/12/79 RESOLUTION BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF LUBBOCK: THAT the Mayor of the City of Lubbock BE and is hereby authorized and directed to execute for and on behalf of the City of Lubbock Change Order No. 4 with Anthony Mechanical, Incorporated, for a time extension of 42 days on contract for improvements to the Southeast Water Reclamation Plant of the City of Lubbock. A copy of the Change Order No. 4 is attached herewith which shall be spread upon the minutes of the Council and as spread upon the minutes of this Council shall constitute and be a part of this Resolution as if fully copied herein in detail. Passed by the City Council this 12th day of February ,1981. LL McALISTER, MAYOR ATTEST: Evelyn Gaf fga, City SejftoE�r,�-Treasurer APPROVED AS TO CONTENT: C/ �4= Guy Wilson, Utilities Engineer APPROVED AS TO FORM: J. W itAl Fullingim, Assistant6lity Attorney RESOLUTION #718 - 2/12/81. -� Amends Reso. #369 - 12/12/79 Change Order No. 4 Phase No. 1 Renovation of Plant No. 1 S.E. Water Reclamation Plant G. W. 0. 10982 TO: Anthony Mechanical, Inc. P. 0. Box 2706 Lubbock, Texas 79408 Original Amount of Contract $ 408,059.00 Change Order #1 1,599.00 Amended Amount of Contract 409,658.00 Original Date of Completion September 16, 1980 Change Order #2 (Additional Time of Completion) 19 weeks Amended Date of Completion January 27, 1981 Change Order #3 $ 1,413.00 Amended Amount of Contract $ 411,071.00 Change Order #4 (Additional Time of Completion) 42 days Amended Date of Completion March 10, 1981 WHEREAS, it is desirable to make changes in the plans and specifications for this project: THIS AGREEMENT WITNESSETH: In consideration of the mutual advantages gained, the Owner and the Contractor agree to the change shown herein and in the attached exhibits and data, and the Owner and the Contractor agree that the original contract between them shall be modified and amended to the extent herein indicated. IN WITNESS WHEREOF, the Owner and the Contractor have hereto set their hands this the 12th day of February, 1981. Anthony Mechanica Inc. y CITY OF LUBBOCK OWNER By yor ' ATTEST: S cretary - Treasurer REC0 'NDED R APPROV : Chiengineer, Water Utilities Engin ring CONTRACT STATE OF TEXAS COUNTY OF LUBBOCK THIS AGREEMENT, made and entered into the 12th day of December A.D. 1979, by and between the City of Lubbock, of the County of Lubbock and State of Texas, acting through Dirk West, Mayor thereunto duly authorized so to do, Party of the First Part, hereinafter termed Owner, and Anthony Mechanical, Inc. of the City of Lubbock , County of Lubbock and State of Texas , Party of the Second Part, hereinafter termed CONTRACTOR. WITNESSETH: That for and in consideration of the payments and agreements hereinafter mentioned, to be made and performed by the party of the First Part (OWNER), and under conditions expressed in the bond bearing even date herewith, the party of the Second Part (CONTRACTOR), hereby agrees with the said Party of the First Part (OWNER) to commence and complete the construction of certain improvements described as follows; PHASE NO. 1 RENOVATION OF PLANT NO. 1 SOUTHEAST WATER RECLAMATION PLANT G.W.O. 10982 and all extra work connection therewith, under the terms as stated %.; in the General Conditions of the agreement; and at his (or their) own proper cost and expense to furnish all the materials, supplies, machinery, equipment, tools, superintendence, labor, insurance and other accesso- ries and services necessary to complete the said construction, in accor- dance with the conditions and prices stated in the proposal attached =_? hereto and in accordance with the General Conditions of the Agreement, E and in accordance with the Plans, which includes all maps, plats, blue prints and other drawings and prints or written explanatory matter there- f, of, and the Specifications therefore, as prepared by the WATER UTILI- TIES ENGINEER, each of which has been identified by the endorsement of the CONTRACTOR and the ENGINEER thereon, together with the CONTRAC- TOR'S written proposal, the General Conditions of the Agreement, and the Construction Bond hereto attached, all of which are made a part hereof and collectively evidence and constitute the entire contract. The CONTRACTOR hereby agrees to commence work within ten days after the date written notice to do so shall have been given to him, and to substantially complete same within the time hereinafter specified. the CONTRACTOR in current funds for the accordance with the proposal submitted and deductions, as provided in the i thereof as provided therein. parties to these presents have iruplicate in the year and day first The City of Lubbock Part f the First Part (OWNER) IMF BY e t ( R) Anthony Mechanical, Inc. Contractor, Corporation, Partnership Party of the Second Part By C� TITLE Complete Address: Anthony Mechanical, Inc. BOX 2706 Lubbock, Texas 79408 No Text